BAILII [Home] [Databases] [World Law] [Multidatabase Search] [Help] [Feedback]

England and Wales High Court (Technology and Construction Court) Decisions


You are here: BAILII >> Databases >> England and Wales High Court (Technology and Construction Court) Decisions >> Hurst Stores and Interiors Ltd. v M.L. Europe Property Ltd. [2003] EWHC 1650 (TCC) (25 June 2003)
URL: http://www.bailii.org/ew/cases/EWHC/TCC/2003/1650.html
Cite as: [2003] EWHC 1650 (TCC)

[New search] [View without highlighting] [Printable PDF version] [Help]


Neutral Citation Number: [2003] EWHC 1650 (TCC)
CLAIM NO: HT-02-322

IN THE HIGH COURT OF JUSTICE
QUEEN'S BENCH DIVISION
TECHNOLOGY AND CONSTRUCTION COURT
MR RECORDER COLIN REESE Q.C.

Royal Courts of Justice
Strand, London, WC2A 2LL
25th June 2003

B e f o r e :


____________________

HURST STORES AND INTERIORS LIMITED
Claimant
and

M.L. EUROPE PROPERTY LIMITED
Defendant
____________________

Mr MARCUS TAVERNER QC appeared for the Claimant, instructed by Walker Morris (Leeds)
Mr PAUL DARLING QC appeared for the Defendant, instructed by Wragge & Co (Birmingham)

____________________

HTML VERSION OF JUDGMENT
____________________

Crown Copyright ©
    COLIN REESE QC
    (Recorder – sitting as a Deputy Judge of TCC)

    BACKGROUND

  1. The Defendant, M.L. Europe Property Limited, a Cayman Island company

  2. "MLEP", is the corporate vehicle used by Merrill Lynch for the development of its
    new European headquarters buildings in the City of London. The development is
    located on a site bounded by Giltspur Street (West), St Bartholomew's Hospital
    (North), King Edward Street (East) and Newgate Street (South). The project
    comprised the construction of two substantial new buildings the "main building" and
    the "west building", and the refurbishment of certain existing buildings, namely the
    Public Office Building ("POB") and No's 114 to 124 Newgate Street ("Newgate
    Street buildings").

  3. The professional team assembled by MLEP for the project included Mace

  4. Limited ("Mace"). Mace was the "Construction Manager" named in the trade
    contracts which MLEP made with various "Trade Contractors". It is common ground
    that at all material times Mace acted as leader and co-ordinator of all the Trade
    Contractors and carried out all administrative functions in respect of the Trade
    Contractors (see paragraph 5 of the Defence and paragraph 3 of the Reply). The
    particular member of Mace's staff who features in this case is Mr David Rumsey. In
    the early months of 2001 he was the person dealing with accounting/payment matters
    for the Claimant, Hurst Stores and Interiors Limited, ("Hurst").

  5. Hurst contracted to undertake extensive toilet fit-out works. The "Trade

  6. Contract Sum" stated in the contract for these works was £2,397,884.17. This sum
    included "preliminaries" of £556,688, the breakdown of which can be found at page
    35 of the annex to the Trade Contract. The contract was negotiated at the end of
    1999 but the formal contract under seal was not made until 18th October 2000, months
    after the works had begun. The contract operated retrospectively to govern the
    relationship of the parties from commencement of the works.

    The two particular members of Hurst's personnel who feature in this case are Mr
    Michael Grant, Hurst's Commercial Director, and Mr James Mell, Hurst's Project
    Manager.

    The contract provided for the works originally required to be carried out between 10th
    January 2000 and 11th December 2000, with commissioning continuing thereafter up
    to 5th February 2001.

    Mace, as Construction Manager, was empowered to issue formal contract instructions
    ("CMIs") to Hurst. These instructions were sequentially numbered. By CMIs 51 and
    288, especially the latter, extensive additional works were instructed. CMI 51 dated
    28th February 2000 (Bundle 10, pages 326 to 326B) reinstated a gym changing room
    which had been included in Hurst's original tender and which had then been omitted
    as a tender adjustment in December 2000. The £11,000 which had been deducted
    from the "preliminaries" when it was omitted was added back to the Trade Contract
    Sum as part of the value of this CMI. CMI 288 dated 28th September 2000 (Bundle
    11, pages 295 ff) added extensive additional works which I describe in more detail
    later (see paragraph 11 below). At this point, I simply note that this CMI recognised
    that time for completion of the contract works, including the additional works, needed
    to be extended by about 4½ months. The Trade Contract Sum increased by
    £832,631.45 which included an addition of £233,462.90 for "preliminaries".

  7. The Trade Contract Works were not in fact completed until about the end of

  8. October 2001. Hurst prepared a "Final Account" dated 26th November 2001 which
    claimed a total of £6,466,205.78 for the works. That sum included a claim for "loss
    and expense" £2,820,413.02, which was broken down into "additional preliminaries"
    of £241,040.31 and "disruption" of £2,579,372.71.

    The additional preliminaries claim was computed by reference to actual (or deduced)
    contract rates which were then applied (in most instances) to the 95 weeks of Hurst's
    site involvement. The sums which had been included for preliminaries in the original
    contract sum, in CMI 51 and in CMI 288 were deducted to leave an unrecovered
    balance, which Hurst claimed, of £241,040.31.

    The disruption claim was computed by calculating the "total cost of site labour" and
    then deducting amounts recovered elsewhere plus an amount for work which Hurst
    accepted it had been at fault. Hurst thereby arrived at an extra over sub-total of
    £1,473,927.26. An uplift of 75% was then applied, on the basis that this was the
    tender allowance for overheads and profit, to produce the claim of £2,579,372.71 (see
    Bundle 3 at pages 37 to 43 for details). In the context of the present case, the factual
    merit of this very sizeable claim does not fall to be considered but, the method
    adopted to calculate the claim should be noted. What was claimed was the calculated
    shortfall in recovery of labour costs over the whole period of Hurst's involvement on
    site. The claim was not limited to disruption costs incurred after 27th April 2001 – the
    significance of that date is explained below.

  9. Hurst justified its Final Account claims on the basis that it works had been

  10. delayed/disrupted because preceding works, particularly the external walls to the
    toilet blocks, had not been completed on time; because there had been a late release
    of a large number of toilet blocks in a short space of time (around September 2000)
    which had caused planning and resourcing problems; and because of on going
    problems with the provision of services being installed by other Trade Contractors
    who did not comply with Mace programmes. In summary, Hurst contended –

    "The delayed releases and failure of Mace to manage other Trade Contractors
    involved frustrated all attempts made by Hurst to implement the Works in an
    efficient, economic, sequential and continuous manner, the result was enforced
    fragmentary implementation of the Works. The same factors also compelled the
    deployment of substantial additional and extended resources, including labour, site
    supervision, plant and equipment.

    Relative to the productivity achieved (which is a reflection of the above factors) the
    labour resources actually and necessarily deployed upon the works resulted in major
    loss emerging from the consequential reduction in productivity………..
    It is a matter of record that Toilet B2.3, the last toilet to be fitted out, was the only
    one where the other Trade Contractors complied with the programme. B2.3 was
    completed less than eight weeks after Hurst were given possession of it verifying that
    if the other Trade Contractors had been properly managed by Mace, and programmes
    adhered to, Hurst could have carried out their works in an economic and cost
    effective manner."


    The reference to the toilets at B2.3 was to part of the works added to the contract by
    CMI 288. On any view (see paragraphs 28 and 29 of the Defence for MLEP's case),
    through no fault of its own, Hurst was not able to complete these toilets by 23rd April
    2001. According to Hurst's claim, the area concerned was not made available until
    10th September 2001 and the works were completed by 31st October 2001.

  11. Hurst's Final Account was hand delivered to Mace on 27th November 2001.

  12. Mace refused to accept it. Mace returned it the same day with a covering letter which,
    in closing, Mr Paul Darling QC, who appeared for MLEP, submitted contained
    "colourful and on one view flippant language." I agree; so far as material and worthy
    of being quoted, the letter made the following point –

    "We had already got an agreed and signed final statement of account for all works up
    to 27th April 2001, as agreed with [Mr Mell]……."


    Faced with the rejection of its Final Account, on 18th December 2001, Hurst referred
    the matter to adjudication. Clause 31.3 of the contract gave either contracting party
    the right to refer any dispute arising in connection with the Trade Contract to
    adjudication under the TeCSA (Technology and Construction Solicitor's Association)
    Adjudication Rules. The 1999 version of the TeCSA Rules provided –

    • that the Adjudicator's decisions should be binding until the disputes

    between the parties were finally resolved (Rule 14); and
    • that although the Adjudicator's decision(s) was (were) to be in writing, it

    (they) should not give reasons (Rule 27).


  13. Mr Matthew T Molloy was appointed as the Adjudicator. He received

  14. voluminous written submissions. He convened a hearing on legal issues and a
    meeting with factual witnesses before he made and published his Decision on 7th
    February 2002. As Mr Darling conceded in the course of his final submissions, Mr
    Molloy's Decision does not bind the Court but, in order to understand the rationale for
    and the form of these proceedings, it is necessary to note which particular aspects of
    the Decision the Court is (in effect) being asked to reconsider.

  15. The differences between Hurst and MLEP which Mr Molloy identified

  16. concerned the value of variations (just under £72,000 was in issue), the claims for
    additional preliminaries and disruption (which were totally in issue) and Hurst's
    entitlement to interest on unpaid sums. He summarised the rival contentions in this
    way –
    "[MLEP's] primary case is that, as Hurst have not complied with the notice
    provisions contained within Clause 17.2 of the contract in respect of extension of
    time and/or loss and expense, Hurst's claim for additional preliminaries and
    disruption must fail. Further [MLEP] contend that Hurst has compromised its
    claims by virtue of Hurst's Project Manager, Mr Mell, signing a Stage 1 Final
    Statement of Account on 27th April 2001 ("the 27th April 2001 Document") and
    the existence of an Interim Statement of Account dated 4th September 2001 ("the 4th
    September 2001 document"). In reply to [MLEP's] primary case in relation to
    notices, Hurst contends that:-
    (i) Hurst did comply with the notice provisions contained within
    Clause 17.2 of the contract,
    (ii) alternatively that the detailed notice provisions contained within
    Clause 17.2 of the contract were varied,
    (iii) alternatively that, by virtue of a letter dated 11th February 2001 sent
    to Hurst by Mace ….. [MLEP] is estopped from relying on the
    detailed notice provisions contained within Clause 17.2 of the
    contract or
    (iv) alternatively, that Hurst is entitled to the sums claimed as damages
    arising from [MLEP's] breaches of contract.
    In respect of the 27th April 2001 Document, Hurst contends that the document
    is limited to the valuation of Construction Manager's Instructions (CMIs") 1 to
    399 inclusive and does not compromise its claim for additional preliminaries and
    disruption. In respect of the 4th September 2001 document, Hurst contends that it
    cannot compromise its claims as it is not signed.

    [MLEP's] secondary case is that, even if Hurst were able to ignore the notice
    provisions contained within the contract in respect of extension of time and/or loss
    and expense, Hurst's claim is global and that, as it does not evidence cause and
    effect, it must fail. In reply, Hurst contends that its claim is not a global claim or,
    alternatively, if it is a global claim, that this is not fatal to its claim for additional
    preliminaries and disruption."
    [my emphasis and, for convenience, I shall also adopt the expression "the 27th April
    2001 Document"]


    Mr Molloy mentioned in his decision that MLEP had requested that he gave reasons
    but Hurst had not agreed that he should. In the absence of agreement between the
    parties, he said that he was obliged by Rule 27 of the TeCSA Rules not to give
    reasons. The decision indicates that although Mr Molloy appears to have been
    unimpressed by MLEP's reliance on the notice provisions contained in Clause 17.2 of
    the contract, he accepted MLEP's contentions that Hurst had compromised the claims
    for additional preliminaries and disruptions. The relevant part of his decision was –

    "THE 27th April 2001 Document

    Does the 27th April 2001 Document constitute a binding agreement between Hurst and
    [MLEP] ?
    34. I find that the 27th April 2001 Document does constitute a binding agreement
    between Hurst and Merrill Lynch.

    If so, what is its nature, scope and effect ?
    35. I find that the nature of the 27th April 2001 Document is that of a compromise
    agreement.
    36. I find that the scope of the 27th April 2001 Document is that it covers the valuation
    of work covered by CMIs 1 to 399 inclusive and Hurst's claims (other than VAT)
    arising out of or in connection with the Trade Contract Works which had accrued up
    to and including 27th April 2001.
    37. I find that the effect of the 27th April 2001 Document is to prevent Hurst from
    making a further claim for any additional costs directly or indirectly associated with
    CMIs 1 to 399, inclusive and from making a claim for any cause of action which had
    accrued up to and including 27th April 2001.

    Does it prevent Hurst from making any of the claims in Referral Notice and, if so,
    which?
    38. I find that the 27th April 2001 Document prevents Hurst from making the following
    claims in the Referral Notice:
    (i) The claim for additional monies in respect of CMIs 176, 177 and 225.
    (ii) The claim for 19 weeks of additional preliminary associated with the
    additional works instructed under CMI 288.
    (iii) The claim for 19 weeks of additional preliminaries associated with the delay
    in handover of areas affected by CMI 288.
    (iv) The claim for disruption arising from events which had occurred up to and
    including 27th April 2001…………

    EXTENSION OF TIME

    What is Hurst's entitlement in respect of its claim for an extension of time ?
    45. I find that Hurst is entitled to an extension of time of 47 weeks to 31st October 2001.
    DISRUPTION

    Was Hurst disrupted by events for which it is entitled to recover loss and expense and/or
    damages and, if so, what events and where ?
    46. I find that, having regard to my findings in relation to the 27th April 2001 Document,
    Hurst was disrupted by events which it is entitled to recover damages in [respect of
    certain identified areas/events].

    What is Hurst's entitlement in respect of its claim for additional preliminaries ?
    48. I find that Hurst is entitled to the gross sum of £59,867.65 in respect of its claim for
    additional preliminaries in respect of the 7-week delay caused by the late handover of
    B2.3.

    What is Hurst's entitlement in respect of its claim for disruption ?
    49. Whilst I have found that Hurst has been disrupted, I am unable to find that the effect
    of the disruption events, taken as a whole, was to either have such a complex
    interaction thereby rendering a specific relation between event and money
    consequences impossible or impracticable, or that the events, taken as a whole, have
    caused the losses claimed. Further, I am unable to make an assessment on the
    recoverable losses based on the material set out and contained in the Referral. I
    therefore make no finding as to Hurst's entitlement in respect of its claim for
    disruption.

    What is the gross valuation of Hurst's final account ?
    50. I find that the gross valuation of Hurst's final account excluding interest is
    £3,640,570.72 exclusive of Hurst's recoverable losses in respect of disruption.

    What is Hurst's entitlement in respect of its claim for interest ?
    51. I find that Hurst is entitled to the sum of £1,596.47 in respect of its claim for interest.


    The overall result of the adjudication was that MLEP was ordered to pay a further
    £65,110.58 (net of a 1½% retention on the value of the contract works) to Hurst.

    ISSUES

  17. These proceedings were begun by Hurst in August 2002. The claim was for

  18. four declarations. The first three declarations require the Court to consider whether
    the conclusions stated by the Adjudicator at paragraphs 35 and 36 of his Decision,
    which are provisionally binding on the parties, should be overruled. The fourth
    declaration represents Hurst's ultimate fall back position. It requires the Court to
    consider whether MLEP is estopped from relying on the 27th April 2001 Document
    as a binding compromise agreement which (ex hypothesi) the Court has agreed it is.
    During the course of closing submissions on 6th May 2003 Mr Marcus Taverner QC,
    who appeared for Hurst, informed me that the claim for the fourth of the declarations
    was "not pressed" but it was not formally withdrawn and, accordingly, I must deal
    with it – albeit, I do so as briefly as I can in view of what I perceive to be its self
    evident lack of merit if (which must be assumed) all of Hurst's other claims have
    failed.

    Hurst also claimed rectification of the 27th April 2001 Document. This claim
    followed on as the logical consequence if Hurst's unilateral mistake case, which was
    the third of the declarations claimed, succeeded. The declarations which Hurst claims
    are –

    (1) a declaration that the 27th April 2001 Document was not a binding
    compromise agreement because consideration was absent and/or because it was not
    signed by either MLEP or by Mace – see paragraph 27 of the, Particulars of Claim;
    further or alternatively,

    (2) a declaration that Mr Mell did not have authority (actual, implied or
    ostensible) to make a binding compromise agreement in the terms of the 27th April
    2001 Document because it was outside the terms of the Trade Contract. Hurst
    admitted that Mr Mell had authority to make agreements as part of the contractual
    mechanism but, Hurst contended that he could not bind the company outside the terms
    of the Trade Contract - see paragraph 28 of the Particulars of Claim; further or
    alternatively,

    (3) a declaration that the 27th April 2001 Document was entered into on the basis
    of a unilateral mistake – the mistake being Mr Mell's mistake; he believed that the
    process upon which he was engaged between January and early April 2001 involved
    his agreeing only labour, plant and materials costs for CMI's 1 to 399; after
    agreement on those matters had been reached with MLEP (Mr Rumsey), MLEP
    prepared the 27th April 2001 Document containing additional terms. This document
    was then presented to Mr Mell without expressly drawing his attention to these
    additional terms. Mr Mell signed the 27th April 2001 Document without reading it
    and/or paying little attention to it because he believed that it did no more than confirm
    what had already been agreed. If this declaration were to be made then Hurst
    contends that the 27th April 2001 Document should be rectified so as to remove the
    reference to its being made in full and final settlement of all claims arising out of or in
    connection with the Trade Contract Works which had accrued up to and including 27th
    April 2001 - see paragraph 29 of the Particulars of Claim; further or alternatively,

    (4) a declaration (which as I have said Mr Taverner did not press) that MLEP was
    estopped from contending that the 27th April 2001 Document was a binding
    compromise agreement otherwise than in relation to the direct costs of CMI's 1-399 -
    see paragraph 30 of the Points of Claim.

  19. MLEP does not accept that Hurst is entitled to any of the declarations or the

  20. rectification which is claimed. MLEP contends that, as Hurst's project manager, Mr
    Mell had authority to deal with all matters concerning progress and payment under the
    Trade Contract; that he had authority to sign the 27th April 2001 Document on behalf
    of Hurst or in the alternative he was "clothed with such authority"; that he
    compromised Hurst's claims (up to a point in time) by signing the 27th April 2001
    Document on Hurst's behalf; that there was consideration for the compromise
    agreement recorded in the 27th April 2001 Document; and, that Hurst is estopped
    from denying that compromise and from attempting to bring additional claims for loss
    and expense for events prior to 27th April 2001 (the representation relied upon being
    the signing of the 27th April 2001 Document – the detriment relied upon being
    payment of the agreed sum, being unable or in a worse position to assess Hurst's
    claims and being deprived of the opportunity, which timely notification would have
    provided, to take steps to avoid the disruption) – see, in particular, paragraphs 7, 12,
    36, 41, 42, 45, 46 and 49 of the Defence. MLEP contends that in about January 2001
    it asked Hurst to prepare a draft final account. MLEP pleaded the motivation for the
    request and the sequence of material events which occurred between January and
    April 2001 and the effect of the 27th April 2001 Document as follows –

    "14. ………. It is admitted that in or about January 2001, [MLEP] asked [Hurst]
    to prepare a draft final account. It is denied that [MLEP] wished to agree a
    figure for labour, plant and material costs only for CMI's 1-399 ……. .
    Such final account was to include all sums/claims owing to [Hurst] up to a
    given date.

    15. The reason for [MLEP's] request was to be in a position to agree [Hurst's]
    final account up to a point in time (agreed with [Hurst]) and not have to
    revisit any aspect of those work costs up to that point in time. Although it is
    referred to as a final account it would only be so if no further CMI's were
    issued after CMI 399. It is [MLEP's] case, therefore, that this was no more
    than a statement of account as at 27 April 2001…..

    17. ………under cover of a letter dated 12 January 2001, Mr Mell submitted a
    document to MACE that was entitled "Final Account Toilet Fit Out Package
    4200" but was referred to in the covering letter as the "Draft Final account".

    18. ………on or about 22 February 2001 and 9 April 2001, meetings took place
    between Messrs Mell and Rumsey in relation to submitted draft final
    account.

    19. ………at the meeting of 22 February 2001, Mr Rumsey was able to agree
    the value of certain variations with Mr Mell but requested certain additional
    information to be able to agree the remainder of the items.

    20. Such further information was submitted under cover of [Hurst's] letter dated
    16 March 2001. At the meeting on 9 April 2001 the value of the further
    variations were agreed. A cut off date for these purposes was agreed at CMI
    No 399.

    21. Having concluded the agreement of the final account up to CMI No 399
    with [Hurst], Mr Rumsey prepared a Change Request for [MLEP] to agree
    his recommendation for the final account value. The Change Request was
    subsequently approved and accordingly Mr Rumsey prepared a final
    statement of account headed Stage 1 FSA ready for endorsement by
    [MLEP].

    22. Save that………
    (b) It is noted that Mr Mell did not read and/or paid little attention to
    the [27th April 2001 Document];
    paragraph 21 [of the Particulars of Claim – see paragraph 17 below] is
    admitted. It is averred that the whole purpose of the two meetings referred
    to above (as was known to Mr Mell, or ought to have been known) was not
    simply to agree the final value of the CMI's 1-399 but in addition to include
    all claims for additional costs as provided for by the contract. Indeed, in
    signing ISAs [Hurst] was taken to agree and accept "the final valuation of
    the instruction detailed in the interim statement of account" (see clause
    23.6.4 of the Trade Contract………which in certain circumstances gives
    interim statements final effect).

    23. ………..[27th April 2001 Document] as provided to Mr Mell following the
    aforementioned meetings, was signed by Mr Mell on behalf of [Hurst] on 27
    April 2001 "in full and final settlement of all claims arising out of or in
    connection with the Trade Contract Works which have accrued up to and
    including the date of this statement".

    24. Further, the [27th April 2001 Document] itself refers to the fact that the
    Final Payment is accepted by [Hurst] in full and final settlement of all
    claims. It is [MLEP's] case that the specific exclusion of claims in respect
    of Value Added Tax is evidence that the sum covered must be taken to
    include all other claims, including any which might have existed for loss
    and expense or disruption. As such Mr Mell was signing nothing more than
    what he must always have had the power to sign. Each agreed ISA was a
    settlement of all claims the contractor had up to the date of that ISA. There
    is no obligation in clause 23.6.4 for either the Defendant or Mace to sign
    such an interim statement.

    25. The fact that the rights of [Hurst] were reserved in respect of seeking
    adjustments for any further CMIs subsequent to 399 (the latest CMI at that
    date) is evidence that the [27th April 2001 Document] was intended to
    encompass all sums due to [Hurst] up to 27th April 2001. This exercise took
    place with all 90 plus contractors so as to give Mace and [MLEP] cost
    certainty.

    26. Further [MLEP] places reliance on the fact that the existence of the
    compromise agreement is found in, or evidence by, the [27th April 2001
    Document] being in effect a written memorandum of agreement. In the
    premises, it is [MLEP's] case that it is not difficult to discern whether the
    parties have in fact concluded an agreement; the parties' negotiations have
    crystallised into a contractually binding agreement dated 27th April 2001.

    46. ……… It is [MLEP's] case that Mr Mell was aware, or ought to have been
    aware, that the document he was signing on behalf of [Hurst] was in full and
    final settlement of all of [Hurst's] claims arising out of or in connection with
    the Trade Contract Works up to 27 April 2001. Mr Mell's alleged failure to
    read the [27th April 2001 Document] when signing is noted but irrelevant."


    As can be seen, MLEP contends that Mr Mell's failure to read the 27th April 2001
    Document - a fact which was "noted" at paragraph 22(b) of the Defence but said to be
    "alleged" at paragraph 46 of the Defence - was a matter of no legal relevance.

    THE TRADE CONTRACT

  21. As I have already said, at paragraph 3 above, Hurst contracted to undertake

  22. toilet fit-out works, the extent of which was significantly increased by CMI 288. A
    little more flesh needs to be put on the bones. At the time the original Trade Contract
    works were priced not all of the toilet facilities required by MLEP had been
    sufficiently designed/defined. In particular those required in the basement of the
    Main Building (in the area identified as B2.3) and in the buildings which were to be
    refurbished had not been sufficiently designed/defined. Hurst was required to price
    only the designed/defined works required in the Main Building and the West
    Building.

    Drawings/specifications for the toilet fit-out works in the POB, Newgate Street
    buildings and the area B2.3 were forwarded to Hurst in June 2000. Negotiations in
    respect of these proposed additional works continued until the end of September 2000
    when they were formally added to the Trade Contract Works by CMI 288. The
    additional works instructed by CMI 288 were to begin during the initial contract
    period but, at the time they were priced, it was recognised that time needed to be
    extended as shown on Mace's completion programme dated 24th August 2000. The
    negotiated and agreed sum of £832,631.45 (the value of CMI 288) included
    "preliminaries" of £233,462.90 in recognition of, inter alia, an extended contract
    period up to 23rd April 2001.

  23. By Clause 4.10 of the Trade Contract Hurst was required to engage an

  24. adequate number of competent/suitably qualified/experienced personnel to carry out
    the works. In addition, Hurst was required to use its best endeavours to procure that
    identified "key personnel" retained their involvement with the project (unless
    otherwise agreed with Mace) through to completion. Key personnel were not to be
    dismissed without Mace's prior approval (not to be unreasonably withheld) and any
    replacements had to be approved by Mace (again, approval was not to be
    unreasonably withheld). The two persons identified as key personnel were Mr
    Michael Grant, who, as I have said, was Hurst's Commercial Director and Mr James
    Mell, who, again as I have said, was Hurst's Project Manager.

  25. Clause 17 of the Trade Contract provide for commencement, completion and

  26. extensions of time.

    By clause 17.2, Hurst was required to give prompt written notices of delay, or likely
    delay, to whole or part of the Trade Contract Works and to provide details of
    causes/expected effects (including an estimate of the expected delay). The giving of
    the required notices and details was expressed to be a condition precedent to Hurst's
    entitlement to an extension of time and/or loss and expense.

    By clause 17.3, after receipt of due notification from Hurst, if Mace was of the
    opinion that the regular progress of the whole or part of the Trade Contract Works had
    been, or was likely to be, delayed by any of the reasons stated in that clause, Mace
    had either to issue an instruction to accelerate or grant a fair and reasonable time
    extension. The list of events which might give rise to such a time extension
    entitlement included acts of prevention or impedance by MLEP or those for whom
    MLEP was responsible (Clause 17.3.4) and the issuing of CMI's which included a
    variation to the works (Clause 17.3.6).

    By clause 17.4, if Mace granted an extension of time or issued an instruction to
    accelerate, it was required to issue a revised Trade Contract programme with which
    Hurst was then to comply.

  27. Clause 20 of the Trade Contract provided for variations to the Trade Contract

  28. Works. By clause 20.1 Mace was empowered to issue instructions requiring a
    variation. Clauses 20.2 to 20.9 contained detailed provisions concerning the ordering
    and valuation of variations. Clauses 20.3 and 20.4 contemplated the value and effect
    of variations being agreed between Hurst and Mace in advance of the varied work
    being executed. Clauses 20.5 and 20.6 enabled Mace to instruct variations without
    first seeking agreement on value/effect or where agreement on either or both of those
    matters had not been reached and, if that was done, their value/effect remained to be
    ascertained. Clause 20.9 provided for effect to be given to the measurement and
    valuation or variations in payment certificates and by adjustment of the Trade
    Contract sum. In view of the significance which they assumed during the course of
    evidence/argument I set out below clauses 20.3 and 20.4 –

    20.3 Provisos on Variations or Instructions
    Unless otherwise instructed by [Mace] pursuant to clause 20.6, [Hurst] shall not
    execute any Variation required by [Mace] nor comply with any instruction issued by
    [Mace] (save where Clause 3.10 applies and subject to the Clauses 20.5 and 20.6)
    unless [Hurst] shall have first submitted to [Mace] in writing within 5 Working Days
    of [Mace's] Instruction:
    20.3.1 an assessment of the value thereof (including all necessary calculations by
    reference to the Trade Contract Documents);
    20.3.2 an assessment of the time within which the Variation is proposed to be
    executed;
    20.3.3 an assessment of the length of any extension of time to which [Hurst] might
    be entitled under Clause 17;
    20.3.4 an assessment of the amount of any direct disruption costs to which [Hurst]
    might be entitled;
    20.3.5 such other information as [Mace] may reasonable require.
    20.4 Agreeing Trade Contractor's assessments
    [Hurst] and [Mace] shall thereupon take reasonable steps to agree [Hurst's]
    assessments. Subject to the approval of the Cost Consultant, any agreements so
    reached shall be binding on [Hurst] and [MLEP] and if agreement is reached on all
    matters referred to in Clauses 20.3.1 to 20.3.4 [Hurst] shall then execute the
    Variation in accordance with [Mace's] Instruction.


  29. Clause 21 of the Trade Contract provided that the Trade Contract Sum should

  30. not be adjusted or altered in any way whatsoever otherwise than in accordance with
    the express provision of the Trade Contract.

  31. Clause 23 of the Trade Contract provided for payment and certification.

  32. Although most of the clause takes a conventional and fairly standard form, included
    within it, as part of clause 23.6 under the heading "Use of Retention", are two subclauses
    which appear to contemplate a rather different payment mechanism to the
    conventional standard form provisions. When construing Clause 23 of the Trade
    Contract I have in mind that by Clause 1.2.4 all headings are to be ignored, that by the
    final paragraph of Clause 1.2, the words in the Trade Contract are to bear their natural
    meaning; and, that by Clause 1.3 if there are ambiguities or discrepancies between the
    Trade Contract and its annex, the terms of the Trade Contract are to prevail.
    By Clause 23.1 Hurst was to submit to Mace interim applications for payment by
    stipulated dates. Within 14 days of receipt of a duly submitted application Mace was
    to issue a "payment certificate". On receipt of the "payment certificate" Hurst was to
    raise a VAT invoice (in the sum certified) directed to MLEP. MLEP was then to pay
    that invoice within 14 days of receipt. In Clause 23.2 the amount which was to be
    stated as due in a payment certificate was expressed in conventional terms. In
    Clauses 23.4 to 23.6.3 retention (before and after practical completion) was dealt with
    in conventional terms, with the final release of retention monies being made after the
    issue of a Certificate of Making Good Defects. And, in Clause 23.7, final
    certification/payment were also dealt with in conventional terms. However,
    superimposed on this conventional payment regime were two further Clauses viz
    23.6.4, dealing with "interim statements of account" ("ISA's") and 23.6.5, dealing
    with "a final statement of account" ("FSA"). Again, in view of the significance which
    these Clauses assumed during the course of evidence and argument, I set them out in
    full –
    23.6.4 [Mace] will issue to [Hurst] interim statements of account which will detail all
    instructions issued to [Hurst] which will entitle [Hurst] to an adjustment to the Trade
    Contract Sum under the terms of this Trade Contract. [Hurst] will value the interim
    statements of account and shall return the interim statements of account within seven
    days of receipt to [Mace] accompanied by all necessary information, measurements
    and calculations in substantiation thereof. Following agreement by [Mace] [Hurst]
    will be required to signify his agreement and acceptance of the final valuation of the
    Instructions detailed in the interim statements of account.

    23.6.5 Either before or within 28 Working Days after completion of the Trade Contract
    Works, [Hurst] shall send to [Mace] all further documents necessary for the purposes
    of the final measurement and valuation of the Trade Contract Works which will be
    completed within [one month following completion of the Trade Contract Works]. A
    final statement of account for the Trade Contract Works shall be provided to [Hurst]
    by [Mace] and [Hurst] shall signify his agreement by signing and returning such
    statement within seven days of receipt thereof and such signature shall be conclusive
    evidence that the amounts shown therein are accepted by him in full and final
    settlement of the amount of the Trade Contract Sum.


    Paragraph 7 of the Annex to the Trade Contract contained further provisions relating
    to the matter of "accounting in connection with the works". Paragraph 7.1 stated that
    interim application dates would be monthly on dates stipulated by Mace. Hurst would
    receive a disk in Excel 7.0 containing all data required "To submit application and
    agreed works carried out" (sic). Paragraph 7.3 consisted of a detailed schedule of
    application and payment dates, column 2 of which set out the application dates
    stipulated by Mace. Paragraph 7.2 provided further in relation to ISA's in the
    following terms –

    Interim Statement of Accounts
    [Hurst] is to return on a monthly basis priced Interim Final Accounts (in the format and using
    the forms supplied by [Mace] which schedules instructions issued to [Hurst]. Supporting
    details of the sum claimed in respect of any instruction issued are required within 5 working
    days of given instruction. Monies will be deducted if this process is not rigorously adhered to.
    A cash flow should be submitted with each application, which reflects anticipated value of all
    future applications

    .
    The ISA Forms which Mace supplied contained the following wording on the last
    page:
    We have examined the above Interim Statement of Account and we agree:
    The items shown represent a complete list of instructions issued to us under our
    Trade Contract at the current date.
    The values shown represent the full and final value of all the work so instructed and
    nothing further remains to be charged against them.
    The total for the list represents the full and final value of our contract works at the
    date of his statement.
    Current ISA total £[ ]

    Specified Excepted Items……..

  33. Clause 32 of the Trade Contract dealt, inter alia, with a number of general

  34. matters. These included Clauses 32.3 and 32.5 which provided –
    Variation and Waiver
    This Trade Contract may not be varied except by an agreement in writing signed by the
    parties. No waiver by either party of any default by the other shall operate or be construed as
    a waiver of any other or further default whether or not of a similar nature.

    Complete Trade Contract
    This Trade Contract constitutes the complete understanding of the parties concerning the
    Project and supersedes all prior negotiations and agreements (written or otherwise) between
    them.

    THE 27th April 2001 Document

  35. At this point it is convenient to introduce the 27th April 2001 Document.

  36. (Bundle 1, pages 230 to 239 or with other accounting documents in sequence at
    bundle 10, pages 156 to 165). It was produced by Mace and dated 26th April 2001.
    The title given to it by the Adjudicator, which I have adopted, derives from the date
    placed on the document by Mr Mell alongside his signature. Although the document
    contemplated that it would also be signed by someone on behalf of Mace, this was not
    done. Formal admission of this fact came at paragraph 60 of the written closing
    submissions where Mr Darling stated that MLEP accepted that this was so.

    The 27th April 2001 Document was a variant of the monthly ISA statements
    contemplated by Clause 23.6.4 of, and Paragraph 7.2 of the Annex to, the Contract
    (see paragraph 16 above). It showed CMIs 1 to 474 with computer generated ticks
    against each entry in the "Agree? Value" column for CMIs 1 to 399 and unticked
    "0.00" entries for each of CMIs 400 to 474. The intended significance of the
    computer generated ticks as part of the interim contractual accounting procedures is
    explained at paragraph 25 below.

    The 27th April 2001 Document differed from the monthly ISA statements in two
    significant respects. First, the bold headings at the top of each page were changed;
    the word "final" was substituted for "interim" in the typescript; the word "draft" was
    added to the typescript but it was crossed through in manuscript and the words "Stage
    1" were added in manuscript. Secondly, in place of the standard wording which was
    included as the last page of each of the monthly ISAs (see paragraph 16 above for the
    text of this) there was a very obviously different last page for this document. It read:

    Total of Final Account 3,445,815.06
    Less total of sums previously paid to the Trade Contractor 2,839,960.90
    ___________
    THE FINAL PAYMENT payable to the Trade Contractor £605,854.16
    In consideration of the agreement that final payment is to be made by the Client, we hereby
    agree that payment to us of THE FINAL PAYMENT will be accepted by us in full and final
    settlement of all our claims (other than claims in respect of Value Added Tax) arising out of or
    in connection with the Trade Contract Works which have accrued up to and including the date
    of this statement.
    We agree that nothing contained in this statement shall relieve us of any of our obligations
    pursuant to the Trade Contract including, but not limited to, our obligations set out under
    clause 8 ("Practical Completion and Defects Liability") of the Trade Contract.
    We agree that, notwithstanding the provisions of the Complete Trade Contract clause (clause
    32.5) of the Trade Contract, the instructions listed in this statement (whether agreed before or
    after the date of the Trade Contract) form part of the contract between the Client and the Trade
    Contractor in relation to the Trade Contract Works.
    If any instructions are issued to us under the Trade Contract after instruction Nr 399 which
    entitles us to an adjustment to the Final Contract Sum, we reserve our rights to seek such an
    adjustment in accordance with the terms of the Trade Contract.
    We hereby agree to the value of the adjusted Trade Contract Price as shown above.


    Mr Mell routinely signed and dated the monthly interim statements for Hurst and, as I
    have already said, he signed the "Final Statement of Account….Stage 1" giving the
    date "27.04.01" alongside his signature. At paragraph 21 of the Particulars of Claim
    Hurst allege that Mace's Mr Rumsey gave that document to Mr Mell who "did not
    read and/or paid [it] little attention….. proceeding on the basis that it merely
    reflected….. agreements [already reached between the two of them]".

    EVIDENCE

  37. Hurst called Mr Michael Grant and Mr James Mell to give evidence. During

  38. the course of closing submissions I was told that Hurst and MLEP had agreed that I
    should be supplied with a transcript of their evidence. This was done and I have had
    the advantage of reading through the transcript (which is generally accurate but there
    are some errors and/or omissions) as well as being able to make my own assessment
    of the witnesses, having seen them and heard them cross-examined. They were the
    only witnesses and gave evidence. At the close of Hurst's case Mr Paul Darling QC
    (Counsel for MLEP) said that MLEP elected not to call evidence. Arising therefrom
    two points should be noted –
    (1) Mr Darling invited Mr Marcus Taverner QC (Counsel for Hurst) to consider
    whether he wished to put in, as hearsay evidence, any of the five witness statements
    which MLEP had served – see CPR 32.5(5). Mr Taverner stated that he did not; and
    (2) prior to hearing oral closing submissions I confirmed with Mr Darling that
    MLEP understood that it was put to its election whether or not to call evidence.
    Accordingly, I now have to consider whether, by the evidence which is before me
    (including the "Statement of Facts" at Bundle 1, pages 38 to 42 insofar as it records
    agreed facts) Hurst has established its case on one or more of the issues raised in these
    proceedings – see generally CPR 32.1.6 and in particular the observations of Mance
    L.J. in Miller –v- Cawley [2002] EWCA 1100 at paragraph 11.


  39. In its closing submissions MLEP expressly and implicitly criticised some

  40. aspects of Mr Grant's evidence (e.g. it was submitted that there was no satisfactory
    evidence provided by Hurst of the circumstances in which Mr Mell's authority was
    conferred on him; and it was submitted that there were no discussions which limited
    Mr Mell's authority – see paragraph 18 of the written closing submissions) but he was
    not personally criticised.

    In contrast, in those same submissions, MLEP expressly criticised Mr Mell who was
    said to be a "deeply unsatisfactory witness" – see paragraph 30 of the written closing
    submissions. MLEP submitted that his evidence was of "little value" because he
    could recollect so little of the events of early 2001 apart from that which could be
    reconstructed from contemporary documents; because of his inability to give
    fluent/articulate answers on some matters (e.g. the meaning of the term "cut-off date"
    in his letter of 12th January 2001); and, because of significant discrepancies between
    parts of his statement(s) made in the adjudication and his witness statement in the
    present proceedings – see in particular, paragraphs 30, 31, 33, 35 and 38 of the written
    closing submissions.

    I do not accept the personal criticisms of Mr Mell and I did not find him to be an
    "unsatisfactory witness". In my judgment, he was an honest witness, entirely lacking
    in guile who did his best to recollect what had happened in the early months of 2001.
    Without the aid of contemporary documents he was unable to recollect the sequence
    of events and, even with the assistance which they gave, he did not pretend to have a
    detailed recollection of the discussions which he had had with Mace's Mr Rumsey.
    He could, however, be sure that certain things were not raised by Mr Rumsey at any
    time during the discussions which took place between January and April 2001 and, as
    to that, I believe his memory is reliable – had these matters been raised not only
    would they have stuck in his memory but, more importantly he would have acted
    differently at the time; most significantly, I think he would have informed Mr Grant
    and involved him in the ongoing process.

    The chronology to which Mr Mell testified was supported by the contemporary
    documents and it was obviously correct – that which had been given in the witness
    statement which he signed in the adjudication was equally obviously misleadingly
    truncated. I do not think that Mr Mell had the contemporary documents in mind when
    he made his earlier statement. Insofar as MLEP drew attention to the wording of
    paragraph 5.1 of Mr Mell's witness statement of 29th January 2003 and contrasted it
    with that to be found at paragraph 25 in his adjudication witness statement of 11th
    January 2002, I do not believe that Mr Mell's unaided recollection had changed over
    the course of the year. I do not think that the personal criticism levelled at him in
    cross-examination and in closing was justified. To my mind, paragraph 5.1 of the
    witness statement was carefully drafted to keep open a possible line of defence and,
    from paragraph 38 of MLEP's written closing submissions this was something which
    was well understood. I am sure that Mr Mell did not personally decide on the
    phraseology used but, when shown the draft, he saw no reason to object and was
    content to adopt it.

  41. Given MLEP's election not to call evidence, I do not know whether Mr

  42. Rumsey has a better, and possibly different, recollection than Mr Mell has of the
    discussions which they had in the early months of 2001 and I have not heard anything
    of events which took place internally, within Mace or between Mace and MLEP
    between 9th April 2001 and 27th April 2001. I draw attention to this latter point
    because, notwithstanding the inclusion of a "Statement of Truth" (signed by MLEP's
    project director) at the end of the Defence, factual allegations made therein do not
    prove themselves at the trial of the action. Unless a factual allegation made in the
    Defence has been admitted (in the Reply), formally agreed in the Statement of Facts
    (Bundle 1, pages 38 to 42) or accepted by Hurst during the trial (e.g. because it is
    apparent from a disclosed document), evidence must be called to prove what was
    alleged. Specifically, I have in mind allegations made at paragraphs 21 and 25 of the
    Defence (cited at paragraph 10 above), most particularly those at paragraph 21. There
    MLEP alleges that, after the meeting between Mr Rumsey and Mr Mell on 9th April
    2001 „ - the meeting itself being an agreed fact (see paragraph 22 of the Statement of
    Facts) „ - Mr Rumsey prepared a Change Request for MLEP to agree his
    recommendation for the final account value and that the Change Request was
    approved by MLEP prior to his preparing [the document which Mr Mell was to sign
    on 27th April 2001] ready for endorsement by MLEP. Hurst did not admit any of
    these allegations in its Reply and I was informed during the trial that no documents
    evidencing and/or supporting them had been disclosed. In the absence of any such
    disclosure, Hurst did not accept any of these alleged facts and I note that, in the
    absence of evidence these allegations remain unproven.

    FACTS/FINDINGS

  43. A number of uncontroversial facts have already been set out above. Here I set

  44. out my findings in relation to unadmitted and/or controversial matters which are (or
    may be) relevant to the issues I have to decide. I begin with the positions/status
    and/or authority of Mr Grant and Mr Mell. In my judgment, their respective positions
    and authorities are clearly stated in the Organisation Chart and the accompanying
    "further details" which, in their final form, were faxed to Mace on 8th December 1999
    (Bundle 1, pages 106 to 109).

    Mr Grant was a director of Hurst and he was notified to Mace/MLEP as the Account
    Director with overall responsibility for the project. He had full authority to act for
    Hurst in all matters, including if it were to arise, agreeing on Hurst's behalf to a
    variation to the terms of the Trade Contract and signing the necessary written
    agreement (see Clause 32.2 cited at paragraph 17 above). In my judgment the fact
    that Hurst notified Mace in July 2000 that Mr Grant was one of the authorised
    contract signatories neither enhanced nor detracted from the authority which he would
    have as a director of the company in any event and/or the general authority which the
    company had specifically conferred on him in relation to this particular project and
    notified to Mace/MLEP.

    Turning to Mr Mell, he was a freelance Project Manager who had previously been
    engaged by Hurst on other jobs. His intended/actual employment status was not
    notified to Mace – and, in my judgment, there was no reason why it should have been.

    This was a matter of indifference to MLEP. When the Trade Contract was being
    negotiated, Mace were informed (by what was said in the Organisation Chart and the
    "further details") that, if awarded the contract, Hurst intended that Mr Mell would be
    its Project Manager. He was to be site based and he was to be responsible for
    successful execution of the project. His position was described in the "further details"
    document which accompanied the Organisation Chart –

    "Jim Mell, Project Manager
    Jim will be based on site and will be responsible for the successful delivery of the project to
    the specified quality, in accordance with the programme and within budget constraints, and for
    producing method statements in accordance with Health and Safety requirements.
    He will be team leader and chief point of contact with Mace…"
    I agree with Mr Darling's submission that it is also relevant to note the functional
    description given for the Quantity Surveyor in the same document –
    "Quantity Surveyor
    One of our Quantity Surveying staff will be allocated to this project to assist Jim Mell. He
    will be head office based with site visits."
    (my emphasis)


    After Hurst was awarded the contract, terms of engagement were agreed between
    Hurst and Mr Mell. Mr Mell was engaged as Hurst's Project Manager from the
    intended commencement of the Trade Contract works. In my judgment, the extent of
    his authority as Project Manager for this project was stated in the Organisation Chart
    and the accompanying "further details" and/or it is to be deduced from the statements
    made therein (read in the context of the Trade Contract as a whole).

    I do not accept the plea at paragraph 7 of the Defence that Mr Mell "… was furnished
    with all the powers and responsibilities traditionally held by a Project Manger" or
    the further plea at paragraph 42 of the Defence that Mr Mell "……. was clearly held
    out as having been appointed by his principal [Hurst] to carry out the duties of a
    project manager" (my emphasis). In my judgment, the title "Project Manager" does
    not, of itself, confer any particular extent of either power or responsibility; it is
    necessary to look at the particular facts of the particular case to see what authority has
    been given to a person with the title "Project Manager". When that is done in this
    case, I agree with the summary which appears at the end of paragraph 7 of the
    Defence - Mr Mell had "express and/or implied power to deal [on Hurst's behalf] with
    all matters concerning progress and payment under the Trade Contract" (my
    emphasis). He was Hurst's team leader and its chief point of contact with Mace;
    insofar as the extent of his authority was not expressly stated, it was implicit (given
    the details of his rτle and the stated fact that the Head Office based quantity surveyor
    would be assisting him) that he had full authority to act for Hurst, in respect of the
    financial aspects of the Trade Contract viz. all accounting requirements and all
    payment matters required by the terms of the Trade Contract, as well as being
    responsible for the proper execution of the Trade Contract Works in accordance with

    the terms of the Trade Contract.

    In my judgment, the emboldened words in the previous paragraph are crucial. Mr
    Mell was not engaged by Hurst to act generally on the company's behalf in the
    management of its business nor did anyone with actual authority to manage Hurst's
    business (e.g. Mr Grant) hold him out as having that authority. Mr Mell was engaged
    by Hurst to act on the company's behalf in the management of a particular project
    undertaken on contractual terms agreed between MLEP and Hurst. It is well
    established that, persons engaged by a contracting party to act on its behalf in the
    fulfilment of a contract, are not to be taken to have power to vary the terms of the
    contract – see Sharpe v San Paulo Railway Company (1873) LR 8 Ch App 597
    where the extent of the authority of the Railway Company's engineer-in-chief in
    relation to the construction of a railway in Brazil was considered. The point was
    succinctly dealt with by Lord Romilly M.R. at page 605, where he contrasted the
    engineer's power to give directions "within the limits of the contract" with his
    inability to vary the contract itself. Of course, a power to agree to vary some or all of
    the contract terms might be expressly given to a particular Project Manager in a
    particular case but, in this case, when Mr Mell's job description is examined no such
    power was expressly given to him and I cannot see any possible basis for its
    implication. Clause 32.2 of the Trade Contract provided for variations to the terms of
    the Trade Contract to be written and signed by the contracting parties; a director of
    the company, Mr Grant, was actively involved with the project and he was notified to
    Mace/MLEP as the person with overall responsibility for it; it was Mr Grant, not Mr
    Mell, who had a general authority to act for the company in the management of its
    business.

  45. During evidence and in argument I was referred to a "contract procedures"

  46. document which Mr Grant had prepared for Hurst's use from 10th November 1997
    onwards. However, this was not a document of which either Mr Mell or Mace had
    knowledge in 2000 and 2001 and, I do not consider that either its existence or its
    contents has any bearing on any of the issues I have to decide. In its Defence, MLEP
    had noted that Mr Mell was one of Hurst's two "key personnel" for the purpose of the
    Trade Contract. I have noted at paragraph 12 above what Clause 4.10 of the contract
    provided in respect of such persons. I accept with Mr Taverner's submission that Mr
    Mell's designation as one of the "key personnel" does not connote any particular
    degree of authority nor can it enhance the authority otherwise given to Mr Mell as the
    Project Manager for this particular project.

  47. In evidence, both Mr Grant and Mr Mell said that Mr Mell was not authorised

  48. to deal with delay and disruption claims.

    Looking at Clause 20.3 (see paragraph 14 above) Mr Mell said that he had authority
    to deal with the assessment of the labour plant and materials value (i.e. Clause 20.3.1)
    and, had it arisen, to provide other information which Mace might require (i.e. Clause
    20.3.5). He said that he was not authorised to deal with time and/or disruption issues
    (i.e. Clauses 20.3.2, 20.3.3 and 20.3.4) – Transcript 45/40-49. He was asked if he had
    ever informed Mace of his authority was so limited. He said he had not; the issue
    "never raised its head" – Transcript 45/50 to 46/4. I have no hesitation in accepting
    that last part of his evidence. Earlier, Mr Grant had explained that Mr Mell had
    estimating experience but he had no experience of dealing with loss and expense
    claims. Looking at Clause 20.3 he said that whilst Mr Mell was able to value CMIs
    involving variations on the basis of the contract rates as required by Clause 20.3.1, he
    would not have been able to deal with the assessment required by Clause 20.3.4.
    However, in Mr Grant's view, Mr Mell's authority was more extensive than Mr Mell
    himself thought it was. In Mr Grant's view Mr Mell was authorised to deal with the
    time issues addressed in Clauses 20.3.2 and 20.3.3 as well as the assessment of value
    required by Clause 20.3.1 – Transcript 6/31 to 13/19.

    Mr Grant said that he thought MLEP and Mace were aware of the limitations on Mr
    Mell's authority – Transcript 13/42 to 46 – but, when the basis for that statement was
    explored, it became apparent that Mr Grant was unable to support it. Not only did the
    terms of the Organisation Chart and the accompanying "further details" go against the
    suggestion but, when the sequence of events leading up to the issue of CMI 288 was
    examined in some detail and when the pricing of CMI 177 was reviewed, it became
    obvious that, so far as Mace was concerned, Mr Mell was the person dealing with all
    aspects of the pricing of these proposed additional works on behalf of Hurst. Mr Mell
    appears to have been personally involved in calculating the extended "preliminaries"
    of £233,462.90 which formed part of the agreed value of CMI 288 (see particularly
    the letter of 6th September 2000 at Bundle 1, page 149 and Mr Mell's evidence –
    Transcript 47/10 to 43, 67/1 to 68/29 and 70/23 to 72/3) and he was also involved in
    calculating the direct disruption costs claimed for unproductive time when CMI 177
    was priced (see Bundle 10, pages 129 and 130, Transcript 60/39 to 45 and for further
    details see paragraph 27 below). These examples demonstrate very clearly that, in
    their evidence, both Mr Grant and Mr Mell were misunderstanding the nature and
    extent of Mr Mell's authority. The fact that he needed to and/or was expected to
    consult internally if and when time or disruption issues arose whereas he was well
    able to deal with pricing by reference to established contract rates without needing to
    and/or being expected to consult internally, did not mean that he lacked authority to
    act, so far as Mace/MLEP was concerned, on Hurst's behalf. In my judgment,
    whatever may have happened internally within Hurst (e.g. assistance provided to Mr
    Mell and/or approvals given by Mr Grant) had no impact of any sort on the ambit of
    the authority conferred on him as Project Manager – see paragraph 22 above.

  49. The operation of the interim contractual accounting and payment mechanism,

  50. throughout 2000 and into 2001 was described by Mr Grant and Mr Mell during the
    course of evidence - Transcript 32/21 to 33/33, 47/45 to 50/19 and 55/35 to 57/33.
    Any month could have been taken as an example but Mr Darling selected the
    documents relating to March 2001, which were dealt with in April 2001 – see Bundle
    12, pages 166 to 189. As envisaged by Clause 23.6.4 of the Trade Contract, the
    process began on 6th April 2001 when Mace wrote to Hurst (Mr Mell) enclosing an
    ISA which listed all the CMIs issued to date. CMI 1 stated the original Trade
    Contract Sum of £2,397,884.17. Many of the CMIs had a typescript "0.00" valuation.
    A comparatively small number of the CMIs had a typescript value (either positive or
    negative) shown against them. A computer generated tick against the value shown for
    the CMI indicated that this value had previously been agreed between Hurst and
    Mace. When forwarded to Hurst, the ISA did not contain any manuscript figures,
    comments or ticks. These were added by Mr Mell to indicate the following –

    • a sum was stated against a CMI with a stated "0.00" value but no computer
    generated tick if Hurst claimed that sum as the value of the CMI.
    • "to follow" was stated against such a CMI if Hurst intended to claim that it
    should be valued but Mr Mell did not yet have a figure to put forward.
    • a manuscript tick was placed against the stated "0.00" value of such a CMI if
    Hurst was prepared to agree that any action required by the instruction did not
    require any adjustment to the Trade Contract Sum.


  51. When cross-examined, Mr Grant was asked about the significance of the ticks

  52. on the ISA Forms – Transcript 32/21 to 50. He said that he understood that a
    computer generated tick meant that agreement had been reached on the value of the
    CMI. He was prepared to agree with Mr Darling's suggestion that, once agreement
    had been reached the figure was something which was finally established for
    contractual purposes. The exchange between Mr Darling and Mr Grant was –

    Mr Darling Was it your understanding that, once that agreement was reached, the figure
    was therefore final?
    Mr Grant In respect of that particular CMI, yes.
    Mr Darling So you were aware of, and operating on the basis of, something being
    finally agreed. Whatever it was that was being agreed, the agreement was
    final?
    Mr Grant The price for carrying out the CMI was agreed. That's my view.
    Mr Darling And was therefore final. You could not come along and say it should be
    more. Mace could not come along and say it should have been less?
    Mr Grant Yes, that's correct.
    (Transcript 32/40 to 50)


    This finality point was also considered in cross-examination, by reference to the
    standard wording which was to be found on the last page of each of the monthly ISA
    statements, which I have set out at paragraph 16 above. Mr Darling drew Mr Grant's
    attention to the middle paragraph – "The values shown represent the full and final
    value of all the works so instructed and nothing further remains to be charged against
    them" – and invited his agreement to the proposition that an agreed value would
    include any entitlement which Hurst might have to "direct disruption costs" under
    Clause 20.3.4 of the Trade Contract. Mr Grant did not agree. In his view, under the
    system which Mace adopted for dealing with CMIs, disruption costs were not
    included in the agreed values – Transcript 31/43 to 32/10.

  53. These issues were explored further with Mr Mell when he was crossexamined.

  54. He was questioned about CMI 177. This CMI was dated 1st June 2000. It
    required the incorporation of disabled toilets within certain locker rooms. An agreed
    value of £8,324.28 had been established. This first appeared as one of Mr Mell's
    manuscript additions to the ISA dated 2nd June 2000 (Bundle 12, page 433) and it was
    incorporated by Mace into the typescript of the ISA dated 10th July 2000 with a
    computer generated tick beside the figure (Bundle 12, page 413). It was then included
    in each monthly ISA thereafter and, given the suggestion of "finality" (put to Mr
    Grant and accepted by him) this figure should simply have continued to be shown on
    the monthly ISAs and, in due course, been shown as part of the FSA – see Clause
    23.6.5 of the Trade Contract at paragraph 16 above.

    The figure of £8,324.28 was the amount shown in Mr Mell's letter dated 25th May
    2000 (Bundle 10, pages 129 and 130). What, to my mind, is self-evidently the Clause
    20.3.1 valuation which Mr Mell said he "put together", was £3,646.24 for the work
    involved in each of the two disabled toilets required plus £172.00 for the additional
    design work i.e. £7,464.48 in total. In addition, Hurst claimed £860.00 for the
    unproductive time involved in relation to one of the two areas where this work was
    required. To my mind, this part of the quotation was a claim for "direct disruption
    costs" covered by Clause 20.3.4 of the Trade Contract. Mr Mell explained that the
    £860 was the charge proposed for 40 hours of actual unproductive time rather than an
    advance assessment of the likely unproductive time which would be involved –
    Transcript 60/3 to 49.

  55. CMIs 177 and 288 were the only ones where the make up of the agreed value

  56. shown on the ISA Forms was explored at the trial. CMI 177 included a figure for
    "direct disruption costs". CMI 288 included a figure for the additional preliminaries
    costs which were agreed between Hurst and Mace to cover the extended contract
    period shown on the programme produced by Mace in August 2000 – Transcript 47/1
    to 33 and see also paragraph 3 above and Bundle 1, pages 149 to 153. The
    justification for these sums is to be found in Clauses 20.3.3 and 20.3.4 of the Trade
    Contract (read together with Clause 17). In his witness statement Mr Mell stated that
    the value agreed for CMI 51 also included a sum for additional preliminaries. He said
    this had been agreed by others on behalf of Hurst and Mace prior to January 2001.
    This part of his evidence was not explored/challenged in cross-examination but, the
    make up of the additional preliminaries of £11,000 which were included in the value
    of CMI 51 is apparent from the documents and I have dealt with this at paragraph 3
    above. I have not attempted to find the make up documents relating to other CMIs –
    they are probably somewhere in the voluminous documentation (originally prepared
    for the adjudication) which was placed before the Court – to see if any of the other
    values included sums in addition to a Clause 20.3.1 valuation of the work involved.
    I do not think this matters. In my judgment, consideration of CMIs 51, 177 and 288 is
    sufficient to illustrate the principles, which are:
    (1) contrary to Mr Grant's stated view, an adjustment to the Trade Contract Price,
    made in respect of varied work (whether agreed in advance as Clauses 20.3.3 and
    20.3.4 envisaged or agreed at some later time), was required to take into account
    additional preliminaries costs (most significantly time related additional costs if a
    time extension was agreed to necessary) and "direct disruption costs" (whether
    estimated in advance or computed after the event), as well as the measured value of
    the works;
    (2) the quotations put forward by Hurst for these CMIs demonstrate that the point
    made at (1) above was in fact understood by Hurst in 2000;
    (3) the variation pricing code set out in Clause 20.3 of the Trade Contract must be
    read in context. In particular, it must be read together with Clause 17 of the Trade
    Contract which, in appropriate circumstances, would allow Hurst to claim loss and
    expense arising from some cause(s) other than the requirement to carry out varied
    work. In other words, claim(s) based on events covered by Clause 17.3.4 happening
    after the variation had been instructed were not excluded (nor was the amount
    claimable restricted) because agreement had been reached on the adjustment to be
    made to the Trade Contract Price in respect of the work itself.


  57. Returning to Mr Mell's marking up of the ISA Forms supplied to him at

  58. monthly intervals, once he had marked up all the items which had not previously been
    agreed, he calculated his figure for the "current ISA total". He substituted his figure
    for that which Mace had stated and he signed and dated the ISA Form (Bundle 12,
    page 176). At the same time as he dealt with that on-going accounting exercise, he
    also prepared the "Trade Contractor Application for Payment" (Bundle 12, page 177).

    To arrive at the payment which was to be claimed, it was necessary to assess the
    progress that had been achieved in respect of each area of the original Trade Contract
    Works and the progress that had been achieved in respect of each of the additional
    works covered by a CMI – to do this percentage assessments were applied to the
    agreed contract values or, where there was no existing agreement, to Hurst's
    estimated contract value. Hurst also calculated a figure for the value of "materials on
    site". The working documents which supported this particular application for
    payment are at Bundle 12, pages 178 to 189. Once Mr Mell had marked up the ISA
    and prepared the Application for Payment, he would put them in an envelope and
    leave it in Mace's site correspondence tray for Mr Rumsey to collect. That was the
    end of Mr Mell's involvement with the accounting and interim payment process –
    paragraph 2.4 of his witness statement at Bundle 1 page 63 and Transcript 57/18 to
    30. Copies of these documents, for which Mr Mell had responsibility were kept on
    site and not sent to Hurst's head office.

    The interim payment certificates issued by Mace after Hurst's application had been
    considered were generally sent direct to Hurst's head office for Mr Grant's attention.
    The invoice, addressed to MLEP, was prepared at Hurst's head office. That invoice
    was sent to Mace who authorised payment and forwarded it to MLEP. BACS
    payments were made by MLEP to Hurst – Transcript 21/16 to 22/27 see e.g. Bundle
    12, pages 374, 392 and 393.

  59. In view of disagreement as to the nature of the "one-off" accounting exercise

  60. which was undertaken by Mr Rumsey and Mr Mell between January and April 2001, I
    think it useful to note the financial position shown on the returned ISA Forms, and in
    the back up documents to the "Trade Contractor Applications for Payment" that were
    current at the time i.e. the December ISA which was issued by Mace on 30th
    November 2000 and returned by Hurst on 8th December 2000 together with the Trade
    Contractor Application for Payment No 37 (Bundle 12, pages 278 to 300 –
    particularly pages 290 and 293 to 300) and the January ISA which was issued by
    Mace on 5th January 2001 and returned by Hurst on 15th January 2001 together with
    the Trade Contractor Application for Payment No 38 (Bundle 12, pages 245 to 277 –
    particularly pages 246 to 253, 266 and 269 to 277). These documents show that the
    vast majority of the CMIs listed – a total of 354 CMIs were listed in the December
    ISA and a total of 373 CMIs were listed in the January ISA – had an agreed "0.00"
    value.

    Twelve CMIs were shown in each of these ISAs with agreed monetary values; in the
    January ISA, a thirteenth CMI – CMI 331 – was added to the list of those where the
    value was agreed because Mace accepted a figure which Mr Mell had stated on the
    December ISA. The CMIs where the value was agreed were –

    CMI No. Brief Description Agreed Value (£)
    1 Appointment of Hurst 2,397,884.17
    58 Certain screeding works 7,569.90
    97 Additional ironmongery 3,217.09
    98 Saving (soap dispensers) (1,587.20)
    106 Telephone charges to Hurst (260.56)
    165 Saving (changes to Specification) (5,300.00)
    168 Addition (changes to Specification) 2,241.45
    176 Saving (changes to Specification) (31,059.00)
    177 Addition (disabled toilets) 8,324.48
    273 Addition (stainless steel mirror surrounds) 2,163.00
    282 Addition (drylining works) 1,160.44
    288 The major additional works 832,631.45
    331 Addition (alterations to lockers/ showers) 12,450.30


    In addition, a number of CMIs were shown as having unagreed "0.00" values. As
    would be expected the latest CMIs, which were featuring on the ISA Form for the first
    time, were shown with such unagreed "0.00" values and these can largely be ignored.
    CMI 274 can also be ignored - here the lack of a computer generated tick appears to
    have arisen either from an error, or from uncertainty on Mace's part as to the meaning
    of Mr Mell's earlier observations. CMI 51 which Hurst had priced at £159,110.65
    appears in this list. As I have said at paragraph 3 above, this CMI concerned the
    reinstatement of a Gym Changing room. It was dated 28th February 2000 and the
    price had appeared in Mr Mell's manuscript on face of the ISA dated 2nd June 2000
    (Bundle 10, page 431). If what Mr Mell said about this CMI in his witness statement
    was correct (see paragraphs 3.2 and 3.3 at Bundle 1, page 64) this figure should have
    appeared in typescript in both the December 2000 and January 2001 ISA Forms with
    a computer generated tick beside it. The only other point that need be noted in respect
    of the twelve of these unagreed "0.00" value CMIs that fall to be considered in this
    litigation, relates to the two of these CMIs which appeared for the first time in the
    December ISA, CMI 331 and CMI 333. These were priced by Hurst in Mr Mell's
    manuscript - CMI 331 at £12,450.30 and CMI 333 at £19,290.37 As I have said
    above, when Mace issued the January ISA the value for CMI 333 was shown to be
    agreed. The twelve CMIs that need to be considered are:

    CMI No. Brief Description Mr Mell's Value (£)
    or Comment
    51 Reinstatement gym changing room 159,110.65
    108 Additional walls 2,106.78
    140 Plasterboard linings 27,908.00
    209 Additional wash hand basin to follow
    210 Mosaic floor sample 1,082.00
    233 Return of submittal to follow
    248 Screed shuttering 562.00
    249 Remedial works to openings to follow
    263 Stop ends to screeds 3,852.20
    285 Installation of rebate kits 2,701.75
    289 Additional screeding 800.00
    333 Variations – Executive Area 19,290.37


    The figures or comments for all these CMIs up to and including CMI 289 had all been
    established by September 2000. They were repeatedly included on the returned ISA
    Forms and used in the payment application calculations (see e.g. Bundle 12, pages 336
    to 341 and 352).

  61. Some time early in January 2001, there was a conversation between Mr

  62. Rumsey and Mr Mell which resulted in Mr Mell preparing a document which he
    entitled "Final Account" which he sent to Mr Rumsey under cover of a letter dated
    12th January 2001. At paragraph 18 of the Particulars of Claim Hurst alleges that "….
    Mr Rumsey ….. asked Mr Mell if it would be possible to agree a figure for labour,
    plant and material costs for CMIs 1 – 399 which [Hurst] was in the process of
    carrying out". MLEP denied this version of the conversation. At paragraph 14 of the
    Defence, cited at paragraph 10 above, MLEP alleges that Hurst was asked to prepare a
    draft final account which was to include "all sums/claims owing to [Hurst] up to a
    given date". No record of the conversation (if any was made) has been produced by
    either Hurst or MLEP. Mr Mell's evidence did not support all the facts alleged by
    Hurst at paragraph 18 of the Particulars of Claim. In particular, Mr Mell's evidence
    did not support a request which specified CMI 399 as the last of the CMIs that was to
    be dealt with as part of a proposed accounting exercise and, for reasons that will
    become apparent, in my judgment the initial request must either have specified an
    earlier CMI number or been couched in a less precise way. I have not heard evidence
    from Mr Rumsey in support of MLEP's pleaded case but it was fully explored with
    Mr Mell in cross-examination.

    I turn to the letter which Mr Mell wrote in consequence of the conversation. The
    letter read:

    "Further to our discussions we herewith enclose draft final account in respect of the above.
    The cut off date is still to be agreed.
    I trust that the information provided meets with your approval."
    (Bundle 1, page 185A)
    The enclosed "Final Account" was a simple document which read:
    Merrill Lynch Financial Centre
    Toilet fit-out
    Package 4200
    FINAL ACCOUNT
    CMI No. 1 Original Contract Value 2,397,884.17
    CMI No. 51 159,110.65
    CMI No. 58 7,569.90
    CMI No. 97 3,217.09
    CMI No. 98 1,587.20
    CMI No. 106 260.56
    CMI No. 108 2,106.78
    CMI No. 140 27,908.00
    CMI No. 165 5,300.00
    CMI No. 168 2,241.45
    CMI No. 176 31,059,00
    CMI No.177 8,324.48
    CMI No. 209 TO FOLLOW
    CMI No. 210 1,082.00
    CMI No. 233 TO FOLLOW
    CMI No. 248 562.00
    CMI No. 249 TO FOLLOW
    CMI No. 263 3,852.20
    CMI No. 273 2,163.00
    CMI No. 274 SEE CMI No. 288
    CMI No. 282 1,160.44
    CMI No. 285 2,701.75
    CMI No. 288 832,631.45
    CMI No. 289 800.00
    CMI No. 331 12,450.30
    43
    CMI No. 333 19,290.37
    Totals 38,206.76 3,476,822.18
    38,206.76
    3,438,615.42
    Additional Items, Requiring CMIs
    1.00 Ceiling Height Reductions
    825.00
    2.00 Additional walls Disabled
    West Core 3 Levels
    486.18
    3.00 Ground Out wall West
    Building 3 levels
    729.27
    4.00 Wall reinstatement Level 1 –
    4 East Core
    2,176.000
    Total to Final Account £3,442,831.87
    (Bundle 1, pages 185B and 185C).


    When this "Final Account" is compared with the December 2000 and January 2001
    ISA Forms, it is apparent that Mr. Mell had done nothing more than list, in numerical
    order, the CMIs which had had values attributed to them (either agreed values or a
    Hurst value), the CMIs where the words "to follow" had been included and, in the
    case of CMI 274, where it had been indicated that its value was included in CMI 288.
    The only additional and possibly new information shown was that given below the
    list, where Mr Mell noted four further items which were said to require CMIs.

  63. The explanation for the production of these documents given by Mr Mell in

  64. his witness statement was, that he had been approached by Mr Rumsey:

    "…..who asked whether it would be possible to agree a cost for a number of the CMIs. Whilst
    there was no particular need for me to do this whilst they were being dealt within the interim
    applications, I did appreciate that Mace were faced with the task of doing this with numerous
    other trade contractors and therefore it would be of assistance to them if we could tie up these
    items. It was certainly of no disadvantage to [Hurst] and it was my understanding that David
    Rumsey was to leave the Project at some stage and certainly it was to Mace's advantage that
    someone with first-hand knowledge was able to deal with this ….

    At Mr Rumsey's request, I submitted a document to Mace headed "draft Final Account" on 12
    January 2001. It was clear that the document could not be a "final" account given that we
    were still on site and so intervening events could effect our actual carrying out of the works.
    Further, there were further CMI's to price which would be included in the final account.
    However, the document was what could be described as the first element of the final
    account as it finalised the cost to carry out CMI's 1 to 399 in terms of labour, plant and
    material together with the additional preliminary costs agreed within CMI's 51 and 288.
    (paragraphs 3.1 and 3.5 of Mr Mell's witness statement – my emphasis)


    Apart from the erroneous reference to CMI 399 rather than CMI 333 in paragraph 3.5
    of the witness statement, the last sentence of this paragraph conveniently encapsulates
    one of the essential submissions which Hurst makes. The description given by Mr.
    Mell to the sum of £3,442,831.87 at which he had arrived as "Total to Final
    Account" is consistent with his believing that the exercise being undertaken was that
    described in this final sentence. Certainly, at the start of the exercise it does not
    appear to have registered with Mr. Mell that he was embarking upon an accounting
    exercise of a markedly different kind to the consideration he had had to give each
    month to the value of the CMIs in order to complete the ISA Form.

    Although Mr Grant was the senior representative of Hurst with whom Mace/MLEP
    had regular dealings, he stated in his reply witness statement that the concept of a
    "final account Stage 1" was never confirmed in writing to him nor was it ever
    announced at the Director's meetings that were held (paragraph 1 of Mr Grant's
    Reply witness statement). This seems surprising if what was being embarked upon
    was an accounting exercise of potential significance and of a markedly different kind
    to the established monthly interim accounting exercises.

  65. A number of matters concerning the nature of the exercise upon which Mr

  66. Mell and Mr Rumsey embarked were explored with Mr Mell in cross-examination.
    On several of occasions during the course of the cross-examination Mr Mell repeated
    his point that the initial discussion (and the subsequent discussions) with Mr Rumsey
    concerned simply valuing CMIs with the purpose of putting the CMIs, up to a certain
    number, "to bed" – Transcript 42/31 to 33, 43/23 and 24, 53/12 and 13 and 63/41 to
    43. Mr. Mell said that at no stage in their discussions had Mr Rumsey stated that he
    was looking for CMIs 1-399 to be priced to include all disruption/loss and expense
    claims. He said that he had regarded the discussions as routine/day to day events at
    which values of some only of the CMIs which, in the overall context, involved only
    comparatively minor sums had been raised. What Mr Mell said appears to me to be
    consistent with what MLEP stated at paragraphs 19 and 20 of the Defence (cited at
    paragraph 10 above).

    Mr Mell was asked why he had used the expressions "draft final account" or "final
    account". He said that he had done so because Mr Rumsey had encouraged the use of
    it – Transcript 42/35 and 36, 43/26 to 50 and 45/12 to 38 – and, at one stage, he was
    prepared to agree with the suggestion made to him by Mr Darling that the likely
    reason why he had used the expression was that Mr Rumsey had asked him to provide
    a final account – Transcript 61/47 to 50.

    He was also asked what he had meant when he had said in his letter "the cut-off date
    is still to be agreed" – Transcript 50/21 to 53/13. Before I heard this part of the crossexamination,

    I had thought I understood this expression. Although I still believe that
    its meaning (objectively ascertained) is clear, it seems that Mr Mell was using
    language rather inappropriately; he appears to have had in mind uncertainty as to the
    last numbered CMI which was to be "put to bed" as part of the exercise which he was
    undertaking with Mr Rumsey. This uncertainty arose in his mind because it was Mr
    Rumsey who would call the necessary meeting(s) to carry the process forward and he
    (Mr Mell) did not know when it (they) would be. I have also noted in this context that
    in the last sentence of paragraph 20 of the Defence MLEP refer to a cut-off date being
    "agreed at CMI 399" (see again paragraph 10 above). This appears to be consistent
    with Mr Mell's usage of the expression.

    However, having noted what Mr. Mell had said in his witness statement and all that
    he said when cross-examined, the overwhelming impression which I had was that Mr.
    Mell was unable to recollect in any detail the conversation which he and Mr Rumsey
    had which had resulted in the letter of 12th January 2001 being written. In my
    judgment, the answers given by Mr Mell to the effect that, beyond being able to recall
    (because he had re-read his letter of 12th January 2001), that it had been preceded by
    some discussions he had no detailed recollection, accurately reflect the position –
    Transcript 53/11 to 41.

    For convenience I also mention at this point that Mr. Mell was equally unable to
    recollect in any detail the follow-up meetings of 22nd February 2001, and 9th April
    2001 and/or the explanatory letters that he wrote on 16th March 2001 and 9th April
    2001.

  67. Mr Mell and Mr Rumsey met to consider this "Final Account" document on

  68. 22nd February 2001. Mr Mell recollected Mr Rumsey making notes at that meeting
    and he was content to accept the note which is at Bundle 1 pages 96 and 97. Mr Mell
    made his own notes (so that he would be able to deal with matters raised by Mr
    Rumsey) which he did not retain after he had prepared his letter dated 16th March
    2001 – Transcript 54/8 to 55/11. Beyond recollecting that they went through the
    "Final Account" item by item, Mr Mell recalled little of the meeting. However, to my
    mind, four things are obvious from the notes themselves – first, they support Mr
    Mell's evidence and what is pleaded at paragraph 19 of the Defence in that Mr
    Rumsey and Mr Mell appear to deal only with CMI valuations – there is no apparent
    attempt to deal with outstanding/potential contractual claims or to obtain confirmation
    that none existed; secondly, it is obvious that whilst some CMI values were agreed at
    the meeting or it was agreed that Mace would be recommending them [presumably to
    MELP], others were to be the subject of further investigations by Mace or further
    substantiation by Hurst; thirdly, it is obvious that Mr Rumsey did not consider that
    previous agreement to a CMI value, as indicated by a computer generated tick on the
    monthly ISA Forms, prevented him from investigating (or further investigating)
    Hurst's prices – see the comments made concerning CMIs 58, 97, 168, 177 and 273;
    and, fourthly, it is obvious that Mr Rumsey did not consider that the value of CMI 51
    had previously been agreed (although he was prepared to recommend the figure which
    Mr Mell had been consistently putting in the monthly ISA Forms and which was
    shown in the "Final Account" of 12th January 20012). Those last two matters may be
    contrasted with the suggestion made to Mr Grant in cross-examination, with which he
    agreed, concerning the finality of an agreement to the value of a CMI (see paragraph
    26 above) and with Mr Mell's unexplored and unchallenged evidence concerning
    prior agreement to the value of CMI 51 (see paragraph 28 above).

  69. Mr Mell wrote to Mr Rumsey on 16th March 2001 providing details/answers in

  70. respect of matters raised at the meeting he had had with Mr Rumsey on 22nd February
    2001 (Bundle 1, pages 210 and 211). The details provided, apparently without
    protest, included details relating to previously agreed CMI values shown on the ISA
    Forms, where Mr Rumsey had requested these.

    It was common ground that Mr Mell and Mr Rumsey met again on 9th April 2001 for
    a further discussion of matters which remained outstanding from 22nd February 2001.
    Although the date when this important second meeting took place was agreed between
    Hurst and MLEP, no file note (if any was made) was produced and there was no
    direct evidence concerning the meeting itself. Mr Mell did not remember the date of
    the second meeting or any of the discussions which took place. Mr Mell simply had a
    general recollection that at some stage he and Mr Rumsey had decided to stop the
    exercise at CMI 399. He said:

    "…. My best recollection is that we stopped at CMI 399, as at the time I was not in a position
    to estimate the cost of CMI 400 due to lack of information on the scope of works involved. I
    note that at paragraph 20 of the Defence, the Defendant's state (sic) that it was at the meeting
    of 9 April 2001 that the cut off of CMI 399 was agreed. I must say that my recollection is that
    the cut off at CMI 399 was agreed earlier than this."
    (paragraph 3.7 of his witness statement)


    What he said there about CMI 400 is supported by the "to follow" observation which
    had been included on the returned ISA Forms for February 2001 and March 2001 and,
    on that point, I accept his evidence. It does not matter whether his recollection
    concerning the timing of the decision to stop the exercise at CMI 399 is correct; it is
    sufficient to say that agreement on this point was reached, at latest, at the meeting on
    9th April 2001.

  71. Mr Mell wrote a further letter to Mr Rumsey dated 9th April 2001 (Bundle 1,

  72. pages 228 and 229). The main matter dealt with in the letter was a breakdown of the
    value of £5,384.00 – which Hurst wished to put on CMI 391. This CMI, which
    covered some additional screeding work, had first appeared on the ISA Form dated
    2nd February 2001 which Mr Mell had returned on 9th February (Bundle 10, pages 216
    to 224). It appears that the work covered by this CMI had been completed before the
    price was agreed since it was included in the Trade Contractor Application for
    Payment No. 39, as being 100% complete. (Bundle 10, page 237). The same details
    had been included in the ISA Form dated 28th February 2001 which Mr Mell had
    returned on 9th March 2001 (Bundle 10, pages 201 and 205 to 214).

  73. It was Hurst's pleaded case (see paragraph 20 of the Particulars of Claim) that

  74. at the February and April meetings Mr Mell and Mr Rumsey had reached agreement
    on the figures which were appropriate for CMIs 1 to 399 (inclusive). This appeared to
    be admitted at paragraphs 19 and 20 of the Defence and, in closing Mr Darling
    submitted that at the meeting on 9th April 2001, final agreement on the figures
    appeared to have been reached. However, in his further letter to Mr Rumsey dated 9th
    April 2001 Mr Mell had referred to "our conversation". It is not clear to me whether
    this was a letter prepared before the meeting, and discussed at it or whether it was a
    letter prepared very promptly after the meeting, as a result of a request made at it. In
    the latter case the agreement at the meeting must have been conditional upon Mr
    Mell's supplying further information which Mr Rumsey would find satisfactory. In
    my judgment, it does not matter whether all figures were finally agreed at the meeting
    on 9th April 2001 or whether Mr Mell's letter followed the meeting, with the
    agreement being finalised once Mr Rumsey had received it and accepted what was
    said.

  75. Documentary support for the fact that agreement was reached prior to 26th/27th

  76. April 2001 is to be found in Mr Rumsey's annotated version of Mr Mell's "Final
    Account" (Bundle 1, pages 212 and 213). Mr Mell was asked in cross-examination
    whether this annotated version of his "Final Account" which had been placed in the
    Court papers immediately behind his letter of 16th March 2001 had been sent as an
    enclosure with that letter (Bundle 1, pages 210 to 211). He said that he did not know
    – Transcript 55/16 and 17. I did not follow that answer up at the time because I
    thought Mr Rumsey would be giving evidence and the annotations seemed to be in the
    same hand as Mr Rumsey's note of the meeting of 22nd February 2001. Looking at
    the second page of the annotated document (Bundle 1, page 213) it is apparent that
    CMI 391 has been added to Mr Mell's primary list of CMIs, with a tick against the
    value of £5,384.00. In my judgment, the probability is that the annotations were made
    (or at least completed) by Mr Rumsey after he received an acceptable breakdown of
    the sum Hurst was claiming for CMI 391 i.e. after he received Mr Mell's letter dated
    9th April 2001. The annotated document also includes what appears to be Mr
    Rumsey's manuscript total of £3,445,815.06. This appears beneath Mr Mell's
    primary list (with the figures adjusted by Mr Rumsey) and the CMI 391 value. This is
    the same figure that appears as the "total of final account" at the top of the final page
    of the 27th April 2001 Document (cited at paragraph 18 above) and, in my judgment
    the probability is that this annotated version of Mr Mell's "Final Account" was the
    working paper used by Mr Rumsey, after he had reached agreement on all the figures
    with Mr Mell, in the preparation of the 27th April 2001 Document.

  77. There is no evidence before the Court of the events which happened between

  78. 9th April 2001 and 26th/27th April 2001. The 27th April 2001 Document appears to
    have been finalised (ready for signature by Hurst and Mace) at some time during 26th
    April 2001 because that is the date shown in the typescript on the first page. It must
    have been provided to Mr Mell on either 26th or 27th April 2001. In paragraph 5.1 of
    his witness statement, Mr Mell said that he did not remember receiving or signing the
    27th April 2001 Document. When cross-examined he readily accepted that he must
    have signed it, because it was obviously his signature on it but he said he had no
    recollection of having done so – Transcript 58/14 and 52. He said at paragraph 5.2 of
    his witness statement that whilst he now appreciated the significance of his having
    signed the document, "I must stress that at the time, this was not a significant event."
    Mr Mell said that he had no recollection of Mr Rumsey explaining to him that the
    final page of the 27th April 2001 Document was different to the final page of the
    monthly ISA Forms or of his explaining to him the intended effect of the document.
    He also said that he had no recollection of dealing with the 27th April 2001 Document
    after signing it. It can be seen that the agreed figures for CMIs 1 to 399 (inclusive)
    were all shown on the monthly ISA forms which were sent to Mr Mell on 4th May
    2001 and 31st May 2001 (Bundle 12, pages 129 to 138 and 105 to 115) and that, in
    contrast to the position with all earlier ISA forms, his manuscript comments on those
    forms begin at CMI 400.

  79. At paragraph 21 of the Particulars of Claim, Hurst alleged that Mr Mell "did

  80. not read and/or paid little attention to the 27th April 2001 Document" before signing
    it because he proceeded on the basis that it merely reflected the agreements of the
    values of CMIs 1 to 399 (inclusive) which he previously reached with Mr Rumsey.
    At paragraph 22 of the Defence, MLEP "…..noted that Mr Mell did not read and/or
    paid little attention to the [27th April 2001 Document]". Whereas at paragraph 46 of
    the Defence MLEP stated, "Mr Mell's alleged failure to read the [27th April 2001
    Document] when signing is noted but irrelevant".

    Mr Mell said, in respect of a statement Mr Rumsey had made – that he (Mr Rumsey)
    had personally handed over the 27th April 2001 Document to him (Mr Mell) – that he
    had no recollection of Mr Rumsey's handing him the document. He questioned
    whether this suggestion was correct. He wondered why Mr Rumsey would have
    departed from the established internal mailing system (paragraph 5.4 of his witness
    statement). At paragraph 23 of the Defence, it is simply stated that the document was
    "provided to" Mr Mell. Given Mr Mell's lack of recollection I am not able to make
    any finding as to the method by which the document was provided to him.

    Whilst Hurst contends that, when Mr Mell signed the document, he believed it merely
    reflected the agreement on CMI values which had previously been reached with Mr
    Rumsey, MLEP's very different view of the nature of the exercise which was
    undertaken and of the agreement between them is apparent from paragraphs 14 and 22
    of the Defence (see paragraph 10 above). Although at paragraphs 19 and 20 of the
    Defence MLEP accepted that, at the meetings on 22 February 2001 and 9th April 2001
    it was the value of variations that was agreed, MLEP contended that the final account
    which Mr Rumsey had wished to receive from Hurst was an account including "all
    sums/claims owing up to a given date"; and, that the whole purpose of the February
    and April meetings "as was known…..or ought to have been known [to Mr Mell] was
    not simply to agree the final value of CMIs 1 – 399 but, in addition to include all
    claims for additional costs as provided for by the Contract."

  81. Having considered these very different views, I prefer Hurst's case. Save to

  82. the extent that I have expressly questioned some aspects of Mr Mell's evidence, I
    accept the evidence which he gave and which I have summarised. I also accept the
    evidence given by Mr Grant which I have summarised. Looking at matters in the
    round, the probability is that if, prior to or on 9th April 2001, something had been said
    to Mr Mell which had alerted him to the fact that Mr Rumsey wished to embark upon
    an accounting exercise of a quite different nature from a routine consideration (or
    reconsideration) of the values to be attributed to individual CMIs for ISA purposes, it
    is likely he would have remembered that, as something unusual/out of the ordinary
    and, and perhaps this is the more important point, at the time he would have reported
    the matter to Mr. Grant. If, on the other hand the exercise was nothing more than a
    routine consideration (or reconsideration) of the values to be attributed to individual
    CMIs with a view to those values being finalised ready to become part of the FSA
    when that came to be prepared, it is unsurprising that no-one should have thought it
    necessary to inform Mr Grant and quite understandable that Mr Mell should have
    regarded it as nothing more than a (useful) routine accounting exercise which, once
    completed, could be placed on the file as a matter of formal record.

    In my judgment, when Mr Mell prepared his "Final Account" of 12th January 2001,
    when he met with Mr Rumsey in February and April 2001, and when he signed the
    27th April 2001 Document, he did not understand that he was being requested to deal
    generally with the issue of contractual claims and to allow for them, and there was no
    reason why he should have thought that he was. Mr Mell can be criticised for not
    reading the 27th April 2001 Document with some care before he signed it, copied it
    (or arranged for someone else to copy it) and placed the copy in the site files.
    However, in my judgment the fact is that he did nothing more than glance at it before
    he signed it. He did not appreciate at the time that he was being invited to do more
    than "firm up" valuation figures which would continue to be included on the ISA
    forms for the remainder of the project and then be taken into the FSA in due course.
    He did not appreciate that, by the terms included on the last page, Mace was inviting
    Hurst to forego any and all as yet unrecognised contractual claims for additional costs
    that it might have. These terms had been included, without any prior hint that they
    were to be there and they were, unfortunately, overlooked by Mr Mell.

  83. Mr Mell left the project of his own accord at the end of June 2001. Mr Grant

  84. telephoned him at the end of November 2001 and asked him about the 27th April
    2001 Document. He was then told that Mace had referred to it in correspondence and
    it had been found in Hurst's site files. Mr Grant said that he was unaware of the
    existence of the 27th April 2001 Document until after Hurst's final account had been
    submitted and rejected. As the responsible Director of Hurst he had full access to the
    files kept on site if he wished to inspect them, but he had not become aware of this
    document whilst the contract was on-going and the site files remained at the site. I
    accept this evidence.

  85. There was a significant body of evidence before the Court concerning events

  86. which happened on the project between May and October 2001. There was
    discussion between Mr Grant and Mr Lewis (Mace's project director) concerning the
    timing of work required in the area designated B2.3 and the appropriate amount which
    should be recognised in respect of extended preliminaries for the work in that area
    (Mace's position), or more generally in respect of extended preliminaries for Hurst's
    ongoing site presence beyond April 2001 (Hurst's position). So far as the issues
    which I have to decide are concerned, these later events (discussions/correspondence)
    were said to be relevant to the estoppel issues but, in my judgment, even if I found in
    Hurst's favour on all matters where there were differences, the pleaded estoppel case
    could not possibly succeed. In the circumstances I decline to make any findings in
    respect of the differences of emphasis and recollection which were identified. I do
    however note that the correspondence from Hurst in 2001, see in particular the letter
    dated 17th September 2001 (Bundle 1, page 246), suggests that Hurst considered that
    considerable disruption costs had been caused to its Trade Contract works between
    May 2001 and August 2001.

    THE DECLARATIONS

  87. I have set out the declarations which Hurst seeks at paragraph 9 above. In

  88. view of the findings which I have made I think it convenient to take the legal issues in
    the following order – unilateral mistake, Mr Mell's authority to bind Hurst in the
    terms of 27th April 2001 Document, the absence of a signature on behalf of MLEP or
    Mace, consideration and estoppel.

    Unilateral Mistake

  89. I take it to be settled law that a mistake made by one contracting party as to

  90. the terms of a contract may, in appropriate circumstances and if the mistake is known
    to the other party, be a ground upon which enforcement of the agreed terms
    (objectively understood) may be resisted.

    Mr. Taverner and Mr. Darling were agreed that, for the purposes of this case, the legal
    principles could be taken from the decision of the Court of Appeal in Commission
    for the New Towns v. Cooper (Great Britain) Ltd. [1995] Ch 259 at pages 277 to
    282 in the judgment of Lord Justice Stuart-Smith and page 292 in the judgment of
    Lord Justice Evans. There the Court of Appeal reaffirmed that in cases of unilateral
    mistake rectification is not ordinarily appropriate because, in general, contracts fall to
    be objectively construed and it is inequitable to compel a contracting party to accept
    the other's mistaken view. But the Court will intervene if there are "additional
    circumstances that render unconscionable reliance on the document by the party who
    has intended that it should have effect according to its terms" Spry, Equitable
    Remedies, 4th Edition at page 599, cited by Lord Justice Stuart-Smith at page 277.


    The debate in this case, as in that case, can be said to turn on what amounts to
    unconscionable conduct. Knowledge of the other's mistake is clearly established to
    be such an additional circumstance but it may be that this is simply a paradigm
    example. Mr Derek Wood QC (who appeared for the Commission) submitted the
    Defendant in that case had been guilty of such sharp and unconscionable practice that
    rectification should be granted. He submitted that the original "bargain" should be
    undone so as to render enforceable the intention which, the mistaken party had if two
    questions received the necessary answers. The questions were –
    (1) Is it unjust and inequitable to hold the mistaken party to the terms of the
    contract ?
    (2) Is it unjust and inequitable to compel the other party to execute a contract in
    the terms that the mistaken party believed to exist ?


    If the answer to the first question is "Yes" and the answer to the second question is
    "No" then, Mr Wood submitted, the Court would rectify the contract. Lord Justice
    Stuart-Smith stated that he saw "great force in this submission" (and in the suggested
    application to the facts of that case). If such an approach were to be adopted, it may
    be that rectification might be ordered in a somewhat wider category of cases than
    those in which it has previously been thought appropriate but, it seems to me that this
    is a case which simply turns on whether Mr Rumsey knew of the mistake which Mr
    Mell had made.

    The Judge in the Commission for New Towns v. Cooper (Great Britain) Ltd case
    had decided that nothing less than proven actual knowledge of the other party's
    mistake was sufficient for rectification. The Court of Appeal disagreed. The Court of
    Appeal drew attention to the careful consideration that had been given to the various
    mental states which might constitute "knowledge", by Mr Justice Peter Gibson in
    Baden v Sociιtι Gιnιrale pour Favoriser le Dιveloppement du Commerce et de
    L'Industrie en France SA (Note) [1993] 1 WLR 509 which was cited by Mr Justice
    Millett J in AGIP (Africa) Ltd v Jackson [1990] Ch 265 at page 293:

    "Knowledge may be provided affirmatively or inferred from circumstances. The various
    mental states which may be involved were analysed by Peter Gibson J. in Baden's case [1993]
    1 W.L.R. 509 as comprising: (i) actual knowledge; (ii) wilfully shutting one's eyes to the
    obvious; (iii) wilfully and recklessly failing to make such inquiries as an honest and
    reasonable man would make; (iv) knowledge of circumstances which would indicate the facts
    to an honest and reasonable man; and (v) knowledge of circumstances which would put an
    honest and reasonable man on inquiry. According to Peter Gibson J., a person in category (ii)
    or (iii) will be taken to have actual knowledge, while a person in categories (iv) or (v) has
    constructive notice only. I gratefully adopt the classification but would warn against over
    refinement or a too ready assumption that categories (iv) or (v) are necessarily cases of
    constructive notice only. The true distinction is between honesty and dishonesty. It is
    essentially a jury question. If a man does not draw the obvious inferences or make the
    obvious inquiries, the question is: why not ? If it is because, however foolishly, he did not
    suspect wrongdoing or, having suspected it, had his suspicions allayed, however
    unreasonably, that is one thing. But if he did suspect wrongdoing yet failed to make inquiries
    because 'he did not want to know' (category (ii)) or because he regarded it as 'none of his
    business' (category (iii)), that is quite another. Such conduct is dishonest, and those who are
    guilty of it cannot complain if, for the purpose of civil liability, they are treated as if they had
    actual knowledge."


    Lord Justice Stuart-Smith cited this passage at pages 280 to 281 and stated that
    categories (i), (ii) and (iii) of Mr Justice Peter Gibson's list all constituted actual
    knowledge in law in the context of an allegation of unilateral mistake. At page 292
    Lord Justice Evans expressly agreed with that view. Lord Justice Farquharson simply
    expressed his agreement in the result. I am bound to follow that decision.

  91. In this case Hurst contends that, if Mr Mell's signature on the 27th April 2001

  92. Document suffices to bind it, the document should be rectified to remove the
    reference to the agreement being made in full and final settlement of all claims arising
    out of or in connection with the Trade Contract works which had accrued up to and
    including 27th April 2001. In practical terms what Hurst seeks is the deletion of first
    paragraph of the text appearing below the figures on the last page of the 27th April
    2001 Document viz. the paragraph beginning "In consideration" and ending "this
    statement" and the deletion of the last two paragraphs of that text viz the paragraphs
    beginning "If any instructions" and ending "as shown above". The full text of these
    paragraphs can be seen in the citation at paragraph 18 above.

  93. Mr Taverner and Mr Darling were agreed that, in order to apply the principles

  94. endorsed by the Court of Appeal in Commissioner for the New Towns v Cooper
    (Great Britain) Limited (supra), it was necessary for the Court to address three
    questions. In view of the findings which I have made the first and the third of these
    questions can now be dealt with summarily. They were –
    had it been proved that Mr. Mell was mistaken as to the contents of the 27th
    April 2001 Document in that it went further than the oral agreement(s) which
    had been reached concerning the values of the CMIs ? and
    had it been proved that the mistake was one calculated to benefit MLEP ?

    It is clear from the findings which I have made, in particular at paragraphs 31 to 41
    above, that my answer to each of these questions is "Yes".

    Mr. Taverner and Mr. Darling differed as to the correct formulation of the second
    question but, as Mr. Darling recognised at paragraph 74 of his written closing,
    whichever I might prefer there was likely to be little practical difference in the result.
    I agree with that observation but I also accept Mr. Darling's submission that it is
    better to avoid the term "suspicion" when formulating the question. Accordingly, I
    pose it in the way he suggested –

    had it been proved that Mr Rumsey had actual knowledge that Mr. Mell was
    mistaken as to the contents of the 27th April 2001 Document or that, in this
    regard, Mr. Rumsey wilfully shut his eyes to the obvious or that he wilfully
    and recklessly failed to make such enquiries as an honest and reasonable man
    would make ?

  95. So far as this second question is concerned, has Hurst proved its case to the

  96. civil standard ? I am conscious that I am considering Mr Rumsey's knowledge in the
    absence of evidence from Mr Rumsey himself. I need to consider carefully what facts
    are agreed/admitted on the pleadings (or later during the case) together with the
    evidence which is before the Court. When it comes to evaluating the evidence
    adduced by Hurst, in the absence of evidence from MLEP, I have in mind the
    observations of Lord Lowry in R v Inland Revenue Commissioners ex parte T.C.
    Coombs & Co. [1991] 2 AC 283 at page 300, to which my attention was invited by
    Mr. Taverner –

    "…..in our legal system generally, the silence of one party in face of the other party's
    evidence may convert that evidence into proof in relation to matters which are, or are
    likely to be, within the knowledge of the silent party and about which that party could be
    expected to give evidence. Thus, depending on the circumstances, a prima facie case
    may become a strong or even an overwhelming case. But, if the silent party's failure to
    give evidence (or to give the necessary evidence) can be credibly explained, even if not
    entirely justified, the effect of his silence in favour of the other party, may be either
    reduced or nullified….."


    Having heard Mr. Mell's evidence concerning of the accounting exercise which he
    and Mr. Rumsey carried out between 12th January 2001 and 9th April 2001 (insofar as
    he could recollect it), having taken into account Mr Grant's evidence that he was not
    informed about the accounting exercise, having considered the facts that were
    agreed/admitted and having carefully considered the contemporary documents, my
    answer to this second question is "Yes".

    In the absence of positive direct evidence as to the way in which the 27th April 2001
    Document was provided to Mr Mell, there are two possible factual situations to
    consider. The first possibility is that Mr Mell signed the 27th April 2001 Document
    in Mr Rumsey's presence. If so, in my judgment, Mr Rumsey probably had actual
    knowledge that Mr Mell was mistaken i.e. he fell into Mr Justice Peter Gibson's first
    category. The alternative possibility is that Mr Rumsey was not present when Mr
    Mell signed the 27th April 2001 Document. If so, in my judgment, the probability is
    that Mr Rumsey was a person falling into either the second or third of Mr Justice
    Peter Gibson's categories, and it matters not which of them he fell into. I explain
    these alternatives more fully below.

  97. The possible factual situations which might have happened are these -
  98. (1) Mr. Rumsey, as he had said in the witness statement upon which Mr. Mell
    commented in his evidence, personally handed the 27th April 2001 Document to Mr.
    Mell and invited him to sign it (without explaining to him that Mace had included in
    the document a previously unheralded invitation to Hurst to forego all as yet
    unrecognised contractual claims up to the date of signature). If he did so and saw that
    Mr Mell signed it without first taking time to read carefully through it, the probability
    is that he had actual knowledge of Mr. Mell's mistake as to the effects of the
    document; alternatively,

    (2) Mr Rumsey, as he had said, personally handed the 27th April 2001 Document
    to Mr Mell (without explaining to him that Mace had included in the document a
    previously unheralded invitation to Hurst to forego all as yet unrecognised contractual
    claims up to the date of signature) but Mr Rumsey did not invite Mr Mell to sign it
    then and there. In the alternative, in line with the established site practice, Mr.
    Rumsey forwarded the document to Mr. Mell for him to collect from the Hurst site
    correspondence tray, (without including a covering note or in any other way drawing
    Mr Mell's attention to the fact that Mace had included in the document a previously
    unheralded invitation to Hurst to forego all as yet unrecognised contractual claims up
    to the date of signature). On either of these possible bases, the probability is that Mr
    Rumsey was wilfully shutting his eyes to the risk that Mr. Mell would not notice the
    newly introduced, potentially prejudicial, words which he had no reason to suspect
    might be there. Alternatively, at the very least, on either of these possible bases, Mr
    Rumsey would have been a person wilfully and/or recklessly failing to take such steps
    as an honest and reasonable man would take if he knew (as on my findings Mr
    Rumsey did know) that the document he had prepared did not simply reflect the
    agreement(s) on CMI values which had been reached earlier that month after
    protracted negotiations.

  99. For those reasons, in my judgment, the 27th April Document 2001 should be

  100. rectified by deleting the paragraphs which I have identified at paragraph 46 above. If
    that is done no difficulty would arise concerning Mr. Mell's authority to sign on
    behalf of Hurst. The document would then record agreed values for CMIs 1 to 399
    (inclusive) which were to be carried forward to the FSA. However, if I am wrong
    about rectification and the 27th April 2001 Document stands in the form that Mace
    put it forward, it is necessary to consider whether Mr. Mell had authority to bind
    Hurst to those terms. I turn to that issue.

    Mr. Mell's Authority

  101. Hurst contends that Mr. Mell did not have authority (actual, implied or

  102. ostensible) to make a binding (compromise) agreement in the terms of the 27th April
    2001 Document because that agreement was something outside the terms of the Trade
    Contract. As I have already said at paragraph 9 above, Hurst concedes that Mr. Mell
    had full authority to agree matters in accordance with the contractual mechanisms but,
    it is contended that he had no authority to bind the company outside the terms of the
    Trade Contract. In my judgment, if Hurst's unilateral mistake case fails then Hurst is
    entitled to the declaratory relief claimed on this basis.

    I have dealt with the extent of Mr. Mell's authority at paragraph 22 above. As I have
    said, he was Hurst's senior site-based representative; he was there (and known by
    Mace/MLEP to be there) to deal with all aspects of Hurst's contract works, but his
    authority did not extend beyond dealing with matters pursuant to and in accordance
    with the terms of the Trade Contract. The Trade Contract contemplated interim
    accounting and interim payments continuing until the project was completed; the
    Trade Contract contemplated the FSA being produced after completion of the Trade
    Contract works – see particularly clause 23.6.4 (taken together with paragraph 7 of
    the Trade Contract Annex) and clause 23.6.5 of the Trade Contract, all cited at
    paragraph 16 above. The Contract did not provide for the production of a "Final
    Statement of Account, Stage 1" whether in the terms of the 27th April 2001
    Document (or in other terms) and, in my judgment if a document of this type was to
    have contractual effect, its production must have been authorised in advance by the
    contracting parties themselves or it needed to be ratified after the event by the
    contracting parties themselves. Given the fact that both contracting parties were
    corporate entities, authorisation or ratification must have been by an appropriate
    individual. In this case, so far as Hurst was concerned, Mr. Grant was the director of
    the company with responsibility for the project. He was the obvious person for
    Mace/MLEP to notify if MLEP desired to vary the contractually agreed accounting
    procedure. He was not informed of such a proposal by Mace/MLEP prior to 27th
    April 2001 nor was he asked to ratify what had been done on 27th April 2001 after the
    event. Mr Mell was not authorised (either expressly or impliedly) to agree to vary the
    terms of the Trade Contract nor did Hurst ever hold him out as having any such
    authority.

  103. The introduction into the established contractual relationship between MLEP

  104. and Hurst of a previous uncontemplated species of final accounting documentation
    could only be done if the Trade Contract terms were varied. If Clause 32.3 of the
    Trade Contract was to be respected the variation would need to be made by an
    agreement in writing, signed by appropriate representatives of the contracting parties.
    That requirement for writing could perhaps have been waived or ignored if directors
    of Hurst and MLEP had reached agreement on some particular proposed variation but,
    it was essential that the agreement be made by persons with full authority to vary the
    terms of the Contract and, as I have said, so far as Hurst was concerned its Project
    Manager, Mr Mell, was not such a person.

  105. On behalf of MLEP, Mr. Darling submitted that there was no real difference

  106. between the monthly ISA accounting exercise and the exercise that had resulted in the
    Final Statement of Account, Stage 1 - see, e.g. paragraph 58 of the written closing
    submissions. On the basis that Mr. Mell's understanding of the exercise being
    undertaken between January 2001 and April 2001 was correct, I would accept that
    submission but, on the basis of the case which MLEP was advancing, I reject it. Mr.
    Darling stressed that under the Trade Contract the interim agreements shown on the
    ISA Forms "were given final effect". In my judgment that is not correct as a matter of
    interpretation of the contract (inter alia, because the ISA Forms dealt only with CMIs
    and not with other aspects of the contract) and, in any event, it was certainly not the
    approach which Mace took with regard to previously agreed CMI valuations during
    the review which Mr Rumsey undertook (see paragraph 34 above).

  107. Accordingly, if the 27th April 2001 Document is not rectified, the conclusion

  108. which I have reached is that no appropriately authorised representative of Hurst
    agreed to it and, the agreements shown therein are not binding. Insofar as values for
    individual CMIs were agreed between Mr Rumsey and Mr Mell and shown on the
    ISA Forms from May 2001 onwards, it may be (but that does not fall for decision in
    this case) that agreements had been made by Mr Mell and Mr Rumsey which were
    within the ambit of each of their respective authorities under the Trade Contract and,
    for that reason, those agreements would remain binding on Hurst.

    The Absence of an MLEP or Mace Signature

  109. In my judgment the declaration sought should not be given. Mace was the

  110. organisation intended to provide a signature to the 27th April 2001 Document. The
    basis of Mace's authority to sign on behalf of MLEP has not been explored in this
    case but, I proceed on the basis that Mace was appropriately authorised by MLEP (or
    that any necessary ratification would have been forthcoming). Mace's failure to sign
    the document is nothing more than an irregularity of no legal significance. Mace had
    drafted the document and put it forward to Hurst for signature; Mr Mell signed it on
    Hurst's behalf; if, contrary to the views which I have expressed, Mr Mell had
    authority to sign it on Hurst's behalf and was not acting mistakenly (to Mr Rumsey's
    knowledge), Hurst would be bound by its project manager's agreement to those terms
    whether or not Mace also signed.

    The Consideration Issue

  111. Here again, in my judgment the declaration sought should not be given. A

  112. sufficient statement of the legal principles can be found in section 3 of chapter 23 of
    Chitty on Contracts (28th Edition). I am of the view that Hurst's contentions on this
    matter are simply misconceived and MLEP's response at paragraph 36 of the Defence
    is over elaborate/unnecessarily complicated.

    Where parties to a contract for work and materials negotiate and agree upon the sum
    which will be paid by one party and be accepted by the other there is an accord (or
    compromise) for which there is ample and obvious consideration. That accord is
    binding on them both. In the normal case, and in this regard I see nothing at all
    abnormal in the facts of this case, the accord provides a new certainty of obligation
    which is substituted for the pre-existing contractual rights (and obligations), the nature
    and extent of which were to some extent at least uncertain/ debatable.

  113. Hurst relies on three matters in support of the plea that there was no

  114. consideration for the agreement contained in the 27th April 2001 Document – the first
    and third of these matters are in reality the same; Hurst avers that the agreement
    concerned the CMI values for CMIs 1 to 399 (inclusive) made between Mr. Mell and
    Mr. Rumsey prior to 27th April 2001, was made "without such agreement being made
    in full and final settlement of all claims which had accrued by 27th April 2001" so that
    the inclusion of the settlement of all such claims in the 27th April 2001 Document
    was "gratuitous". Factually what is contended is entirely in line with the findings I
    have made but, in my judgment, a no consideration plea simply cannot be sustained.
    Once again, proceeding on the basis that Mr. Mell had authority to act for Hurst and
    that he did not act mistakenly (to Mr. Rumsey's knowledge), acceptance of a proposal
    to include all existing (accrued) but as yet unacknowledged claims within the ambit of
    a proposed accord would not adversely affect the accord, if an agreement were
    reached in terms which included these claims. The second of the matters upon which
    Hurst relies is an averment that MLEP was contractually obliged to pay the labour,
    plant and material costs of CMIs 1 to 399 (inclusive). I agree but ask, rhetorically,
    what were the actual sums that MLEP was obliged to pay ? Was there room for
    debate as to the sums properly claimable ? Assuming there was, there was ample
    scope for resolution of the matter by means of enforceable accord.

    Estoppel

  115. Hurst's contention is that the correspondence/discussions between July and

  116. September 2001 concerning its claims for additional preliminaries "amounted to a
    representation by [MLEP] that [Hurst] was entitled to pursue its claims for loss and
    expense which were not compromised, alternatively the parties conducted themselves
    on the conventional basis that this was the position." Hurst then contends that in
    reliance on this representation it incurred substantial costs in pursuing its loss and
    expense claims to adjudication. In the alternative Hurst contends that it would be
    "unjust to allow MLEP to resile from this position."

  117. As I have said at paragraph 9 above, Mr. Taverner did not press this part of the

  118. case but it was not withdrawn. In my judgment this claim fails on every point – the
    evidence of Mr Grant taken together with the documentary materials before the Court
    does not demonstrate any representation of any sort made by MLEP (or by Mace on
    its behalf) in respect of the possible pursuit (by Hurst) of a loss and expense claim; the
    parties did not conduct themselves on any basis that could possibly be described as a
    "conventional basis" with regard to the pursuit (by Hurst) of a loss and expense claim;
    Hurst did not rely on any material representation of any sort made by or on behalf of
    MLEP when it originally decided to put forward a loss and expense claim and/or
    when it decided to pursue that claim in an adjudication. In the circumstances if,
    contrary to the conclusions I have reached, Hurst was bound by the terms of the 27th
    April 2001 Document from the date that Mr. Mell signed it, I find myself unable to
    see any possible basis upon which the pleaded estoppel claim might succeed.

  119. I come finally to MLEP's pleaded "estoppel". Corrected for the obvious

  120. typographical error, the plea at paragraph 49 of the Defence was –

    "49. ……it is [MLEP's] case that in signing the [27th April 2001 Document] [Hurst] is
    estopped from denying that the sums stated were in full and final settlement of all claims as at
    27th April 2001 and from attempting to bring additional claims for loss and expense for events
    prior to 27th April 2001. [Hurst] has made a clear and unequivocal statement that all claims up
    to 27th April 2001 are compromised by payment "of the sum agreed". [MLEP] has acted to its
    detriment on that representation by paying the agreed sum and now being unable or in a worse
    position to assess any alleged claims the Claimant now says it has. Had Mace been made
    aware "timeously" of any alleged disrupting events they might have been able to reprogramme
    or manage other trade Contracts in such a way as to avoid any disruption for [Hurst]."


    Although this part of MLEP's case was maintained with apparent enthusiasm by Mr
    Darling, in my judgment it cannot possibly succeed. No evidence was called to
    support the factual matters raised in the final two sentences (which, at first blush, fall
    to be viewed with considerable scepticism) but, even if they had been established in
    view of the findings I have made in relation to Hurst's claim for a declaration based
    on unilateral mistake and in the alternative, its claim for a declaration based on Mr
    Mell's lacking the necessary authority to bind Hurst to the terms of the 27th April
    2001 Document, I see no possible basis upon which Hurst can be prevented from
    vindicating its true legal rights.

    Costs

  121. Mr Taverner submitted that Hurst should be awarded its full (standard basis)

  122. costs of the action. Basing himself on CPR 44.3 Mr Darling submitted that although
    Hurst had succeeded in obtaining two of the declarations which it had claimed, its
    failure on a number of the factual and legal issues raised should be taken into account.
    Hurst, he said, should be awarded somewhere between 50% and 70% of its costs. I
    accept Mr Darling's submission that Hurst's cost recovery should be limited but, in
    my view a lesser reduction is justified. The extent to which Hurst has failed on a
    number of the factual and legal issues which were raised is apparent from this
    Judgment and I also take into account, as a counter-balancing factor, MLEP's own
    failure on its estoppel case. In my judgment, considering the case as a whole,
    substantial justice will be done if Hurst is allowed to recover 80% of its costs from
    MLEP, and I so order.



BAILII: Copyright Policy | Disclaimers | Privacy Policy | Feedback | Donate to BAILII
URL: http://www.bailii.org/ew/cases/EWHC/TCC/2003/1650.html