TMW PRAMERICA PROPERTY INVESTMENT AGAINST GLASGOW CITY COUNCIL [2017] ScotCS CSOH_152 (13 December 2017)

BAILII [Home] [Databases] [World Law] [Multidatabase Search] [Help] [Feedback]

Scottish Court of Session Decisions


You are here: BAILII >> Databases >> Scottish Court of Session Decisions >> TMW PRAMERICA PROPERTY INVESTMENT AGAINST GLASGOW CITY COUNCIL [2017] ScotCS CSOH_152 (13 December 2017)
URL: http://www.bailii.org/scot/cases/ScotCS/2017/[2017]_CSOH_152.html
Cite as: [2017] CSOH 152, [2017] ScotCS CSOH_152

[New search] [View without highlighting] [Printable PDF version] [Help]


Page 1 ⇓
OUTER HOUSE, COURT OF SESSION
[2017] CSOH 152
CA13/17
OPINION OF LORD TYRE
In the cause
TMW PRAMERICA PROPERTY INVESTMENT GmbH
against
GLASGOW CITY COUNCIL
Pursuer
Defender
13 December 2017
Pursuer: Howie QC; Brodies LLP
Defender: Currie QC; Pinsent Masons LLP
Introduction
[1]       By missives dated 21 December 2011, the defender agreed to sell to the pursuer a
new building in Bothwell Street, Glasgow. The building consisted of office premises and
had been constructed in 2009. The sale was completed on 5 January 2012. It was known to
both parties that the building had a number of defects, and the missives made detailed
provision for rectification of those defects, and for retention by the purchaser (ie the
pursuer) of part of the purchase price pending such rectification. The works required were
set out in a table of 23 items, and were categorised as either priority or non-priority works.
Each of these two categories was assigned a long-stop date, at which time the relevant part
Page 2 ⇓
2
of the retention would become payable to the pursuer unless a substantive start to the
remedial works had been made. In the latter eventuality, the defender’s entitlement to
continue the works was extended to “the Deferred Long Stop Date”, being such further
period of time after the relevant long stop date as the parties might agree as being
reasonable to permit the remainder of the works to be completed. In the absence of
agreement, determination of the Deferred Long Stop Date was to be referred to an
independent expert.
[2]       The works were not completed by the long stop dates. The parties did not agree on
the further time that was reasonable to permit the remainder of the works to be completed,
and in 2015 the matter was referred to an independent expert. On 3 July 2015 the
independent expert issued his decision and note of reasons. For present purposes the
significant feature of the independent expert’s decision is that he identified Deferred Long
Stop Dates for each of the items in the table individually, ie 23 in all.
[3]       In the present action, the pursuer seeks to enforce its entitlement under the missives
in accordance with the independent expert’s decision, seeking (i) declarator that it is entitled
to have sums held in a solicitors’ joint bank account in respect of the retention paid over to
it, and (ii) decree ordaining the defender to consent to the release of those sums. The
defender maintains that the independent expert’s determination is vitiated by error of law
and falls to be reduced, with the consequence that the sums sued for are not due to be paid
over to the pursuer. A further issue has arisen between the parties in relation to the proper
interpretation of a term of the missives entitling the pursuer to recover from the defender
certain professional costs incurred by it; I deal with this issue briefly at the end of this
opinion.
Page 3 ⇓
3
Contract terms
[4]       The terms of the parties’ contract concerning the retention were set out in part 10 of a
schedule to the missives. They are of some complexity. (In this opinion I shall use
capitalisation only for those defined terms whose definition is of significance in the parties’
dispute.) Paragraph 2 provided that on the date of entry, that part of the completion
payment representing the retention (a specified sum) was to be retained by the defender’s
solicitors and paid into a joint account, to be held there on trust with the purchaser’s
solicitors for the purposes set out in the schedule.
[5]       Paragraph 3.1 required the defender to use all reasonable endeavours either (a) to
procure that the Remedial Works were carried out by pursuing its remedies under collateral
warranties, or (b) to carry out and complete the Remedial Works itself, as soon as reasonably
practicable after the date of entry, and in any event to “use reasonable endeavours to have
done so by the relevant Long Stop Date”. “Remedial Works” were defined in
paragraph 1.13 as follows:
“… all (a) investigations, (b) testing, (c) obtaining of any retrospective relaxations or
approvals that the works in question are (and will during the following [sic] the
carrying out of all relevant works be) compliant with building control and other
regulations in force at the time the works in question were originally carried out
(d) works, and (e) retrieval of information or procurement of replacement
documentation which is in each case necessary to remedy each of the issues (insofar
as same existed as at the Date of Entry) identified in the table which forms Part 16 of
the Schedule …”
[6]       The table in Schedule 16 listed 23 “groups” of remedial work. These 23 groups were
variously referred to in the missives as “issues” or “items”; I shall use the word “item” to
refer to them. The 23 items were allocated to one of four “Packages”, being respectively the
Elevation Package (items 1 to 8), the Roof Package (items 9 to 15), the Services & Internal
Package (items 16 to 22) and the Information Package (item 23). Within each package
Page 4 ⇓
4
(except the Information Package) there were items specified as Priority Work, and other
items not so specified. For each item the table included a figure in a column headed “Total”
(although the figure for most but not all of the non-priority items was Nil), and a figure in a
column headed “200%” which in all cases was double the Total. The sum of the figures in
the column headed “200%” was equal to the retention. Within each Package, the figures in
the columns headed Total and 200% were added up to give a figure called the “Sub-Total”.
Each of the figures in the column headed “Total” for Priority Works was defined in
paragraph 1.4 as an “Individual Sum”.
[7]       Paragraph 3.1 also permitted the defender, prior to carrying out any particular item
of Remedial Works, to request the consent of the pursuer not to carry out or procure the
carrying out of Remedial Works (or a part thereof) in whole or in part. If the pursuer in
exercise of its discretion agreed to the request, then the defender would “forfeit the
Retention (or in the case of not carrying out or not procuring the carrying out of part of the
Remedial Works, that part of the Retention relating to the appropriate Package and/or
Individual Sum)”.
[8]       Paragraph 5 dealt with releases of funds from the joint account. The starting point,
set out in paragraph 5.1, was that on “the relevant Long Stop Date”, the defender’s right to
carry out and complete “the relevant Remedial Works” would cease, along with any right of
access to the building. “Long Stop Date” was defined in paragraph 1.6 as follows:
“… (i) for Priority Works the date which is ten months after Completion and (ii) for
all other Remedial Works the date which is twenty four months after Completion as
such date is extended (a) by a reasonable period or periods (to be agreed by the
parties failing such agreement to be determined by an Independent Expert in
accordance with the provisions of this Part 10 to allow for the works in question to be
carried out in a season or during a time that is most appropriate having regard to the
nature of the works in questions [sic] and (b) pursuant to the provisions of this Part
of the Schedule.”
Page 5 ⇓
5
By the end of the debate it was, as I understood it, common ground that there were initially
two Long Stop Dates: one for Priority Works and one for other works. The defender’s
position was that there could only ever be two Long Stop Dates; the pursuer contended that
the number could increase to a theoretical maximum of 23, if extensions were agreed or
determined in accordance with the definition above. I shall return to this issue later. What
in fact happened was that the Long Stop Date in respect of Priority Works was extended by
agreement to 14 February 2014. There was no extension in respect of other works, for which
the Long Stop Date remained 5 January 2014.
[9]       Paragraph 5.2 dealt with the situation where all of the items in a Package were
timeously completed by the defender. In that eventuality the defender was entitled to
payment of the Sub-Total in the “200%” column, ie the full retention for that Package. In
addition, paragraph 5.4 provided that where the defender timeously completed an item of
Priority Works, it was entitled to receive the Individual Sum in respect of that item (ie half
the retention for that item alone).
[10]       Paragraph 5.3 dealt with the situation where all of the items in a Package were not
completed by the defender by the Long Stop Date (or by a later date referred to as the “Cut-
Off Date; see below). In that eventuality, the pursuer was entitled to payment of the full
retention for that Package (under deduction, presumably, of any Individual Sum previously
paid to the defender under paragraph 5.4). This entitlement was, however, subject inter alia
to the provision that lies at the heart of the current dispute, namely paragraph 5.2.1, which
stated:
“Where at the Long Stop Date the Seller has made a substantive start to carry out,
and are continuing in a meaningful way to carry out, any Remedial Works (either by
way of works commencing on site, a building contract having been let, the relevant
statutory consent applications having been lodged) their entitlement to carry out
those particular works shall continue until the Deferred Long Stop Date and their
Page 6 ⇓
6
entitlement to claim the Retention in respect of such works shall continue
appropriately. If those works are not completed by the Deferred Long Stop Date the
Seller’s entitlement to complete those Remedial Works shall cease along with any
right of access to the Property.”
The “Deferred Long Stop Date” was defined in paragraph 1.1 as follows:
“… for Remedial Works to which paragraph 5.3 [parties are agreed that this
reference should be to paragraph 5.2] applies, such further period of time after the
Long Stop Date as the parties agree (or the Independent Expert determines) as being
reasonable to permit the remainder of those works which have been started to be
completed”.
[11]       One further set of provisions requires to be mentioned. Paragraph 3.11 was
concerned with Remedial Works which were “Potentially Service Chargeable Items”, ie,
defects in respect of which liability could potentially be passed on by the defender to a third
party such as the contractor or a member of the design team. “Potentially Service
Chargeable Items” were defined in paragraph 1.10 as “those Remedial Works identified in
the column headed ‘Nature’ as ‘Warranty Recovery/Service Charge Reclaim’ in the table
which forms Part 16 of the Schedule”. Unfortunately in this as in other respects the
draftsmanship of the contract demonstrated a lack of attention to detail. There were in fact a
number of items in the column headed “Nature” identified as “Warranty Recourse/SCR
Repair & Maintenance” and I take those items to be the ones alluded to in paragraph 1.10.
The items in question appear in three of the four Packages. Most, but not all, are non-
priority items. In terms of paragraph 3.11, the defender was obliged to use all reasonable
endeavours to have the relevant third party accept liability for these items, including, where
appropriate, taking matters to adjudication and/or raising court action if there was a
reasonable prospect of success. If by the Long Stop Date such endeavours had failed to
result in third party liability being accepted or determined to exist, the defender’s
obligations in relation to the relevant item were held to be complete. If on the other hand
Page 7 ⇓
7
such liability was accepted or determined to exist, the defender was obliged to carry out the
relevant works. If at the Long Stop Date court or arbitration [sic, not adjudication]
proceedings were continuing, the Long Stop Date was extended until proceedings were
complete and to allow for subsequent completion, within a reasonable time, of the relevant
works.
[12]       It appears that the “Cut-Off Date” referred to in paragraph 5.3 was a reference to
either the Deferred Long Stop Date or a date following an extension in terms of
paragraph 3.11.
The question referred to the Independent Expert
[13]       It is, as I understand it, common ground that no Remedial Works were completed by
either Long Stop Date. It is also, as I understand it, common ground that (with one
exception referred to the independent expert but with which this opinion is not concerned),
a substantive start was made by the defender to carry out the Remedial Works in respect of
all 23 items. The parties could not, however, reach agreement on the amount of time that
would be reasonable to permit the remainder of the works to be completed. The matter was
accordingly referred, in accordance with paragraph 1.6, to an independent expert. The
question referred to the expert for his decision was:
“What period of time after the Long Stop Date (for each Group Item) that would be
reasonable for the remainder of the Remedial Works to be completed (including the
carrying out of any investigations) to determine what the Deferred Long Stop Date
should be for each Group Item”.
Neither party contended that anything turned on the precise wording of the question
referred for determination.
Page 8 ⇓
8
The Independent Expert’s determination
[14]       It is clear from the terms of the expert’s decision that he was well aware that the
parties were in disagreement as to the proper interpretation of paragraph 5.2.1, read
together with the definition of Deferred Long Stop Date. The expert narrated the competing
submissions on this issue at paragraphs 3.7 to 3.19. At paragraph 3.20 he concluded:
“Therefore I can see no impediment in what the Seller asserts with respect to the
access rights or the [Long Stop Dates], to a construction which provides that there be
23 separate Group Items, each with its own “relevant” Deferred Long Stop Date.
This is what is asserted by the Purchaser, and on the basis of the foregoing analysis,
that is also my view.”
The expert proceeded to consider each item of the Remedial Works in turn, and provided in
each case a decision as to the period of time that would be reasonable for the remainder of
the Remedial Works from the relevant Long Stop Date. By this means he determined a
Deferred Long Stop Date for each item individually. Some of those dates were in the past as
at the date of the expert’s decision.
Review by the court of the decision of an expert
[15]       It is well settled, in principle, that where parties have agreed to be bound by the
decision of an expert, that decision cannot be challenged in the courts unless the expert has
departed from the instructions given to him in a material respect: see eg Jones v Sherwood
Computer Services plc [1992] 1 WLR 277. Where, however, a determination is dependent
upon the proper interpretation of a contractual provision, an expert who misinterprets the
contract has not done what he was asked to do. His interpretation is therefore open for
review by the court: see Mercury Communications Ltd v Director General of Telecommunications
[1996] 1 WLR 48 (HL), Lord Slynn of Hadley at 58-9. In the present case it was not
contended on behalf of the pursuer that the expert’s decision to determine a Deferred Long
Page 9 ⇓
9
Stop Date for each of the 23 items individually was beyond the scope of review by the court.
I need not therefore address the general principle further.
Argument for the defender
[16]       On behalf of the defender it was submitted that the schedule provided a coherent
scheme for Priority Works and other works, and for Packages which included works in both
categories. The seller (ie the defender) was to work towards completing Priority Works by
their Long Stop Date and other works by theirs. There was neither provision nor need for a
Long Stop Date for each individual item. It was reasonable to proceed on the basis that this
underlying scheme was maintained when fixing Deferred Long Stop Dates. The reference in
paragraph 5.2.1 to having made a substantive start to carrying out “any” Remedial Works
indicated that if the seller had started works which were continuing at the Long Stop Date
(for either category), then it was entitled to a Deferred Long Stop Date in respect of “those
particular works”, ie in respect of Priority Works or other works, as the case might be. Use
of the singular “the date” in the definition of Long Stop Date in paragraph 1.6 and “the
Deferred Long Stop Date” in the final sentence of paragraph 5.2.1 were further indications
that only one such date was envisaged for each category of works. The reference in the
latter sentence to rights of access ceasing mirrored a similar expression in paragraph 5.1 in
relation to a Long Stop Date: in each case there were two possible dates, not 23. If there was
a separate Long Stop Date for each item, one would expect to see that in the definition.
Significantly, paragraph 5.2.1 made no mention of individual items. The underlying
purpose of the scheme was to withhold full payment of the retention until all of the items in
the Package in question had been completed.
Page 10 ⇓
10
[17]       As to the question whether a Deferred Long Stop Date could have been fixed as a
date prior to the date of the experts’ decision, the language of the scheme was more
naturally read as prospective. On the pursuer’s construction, the defender would have had
to carry out work against an awareness that if any of it was done after the date eventually
fixed as the Deferred Long Stop Date, this would not allow release of the retention. That
interpretation was commercially unsustainable. The defender would not have had any
completion date to target and the pursuer would obtain an unreasonable windfall. The
better construction was that the defender was to be given a date that could then be used to
programme the remaining works.
Argument for the pursuer
[18]       On behalf of the pursuer it was submitted that the purpose of the definition of
Deferred Long Stop Date was to provide an objectively ascertainable period that was
reasonable to complete works already started. Although there were two Long Stop Dates at
the outset, there could in the end be as many as 23. Properly construed, the definition of
Long Stop Date (and in particular the reference to extension for “a reasonable period or
periods”) did not provide for consecutive extensions of the same period, but rather different
periods of extension for individual items of Remedial Works. What the expert had been
asked to do was to fix a reasonable time to complete each item, assessed as at the Long Stop
Date. The Deferred Long Stop Date was therefore, for each item, the Long Stop Date plus a
reasonable period to permit works already under way to be completed. That was what the
expert had determined. The reference in paragraphs 5.2.1 to “any Remedial Works”
indicated that there were more than two Long Stop Dates and Deferred Long Stop Dates: if
there were only two, the expression used would have been “either”. The definition of
Page 11 ⇓
11
Remedial Works in paragraph 1.13, and in particular the words “in each case necessary to
remedy each of the issues”, suggested that the items had to be considered individually.
[19]       It followed from the foregoing that it was possible for the Deferred Long Stop Date
fixed by the expert to be a date in the past, provided only that it could not be earlier than the
Long Stop Date for the item in question. The date of the expert’s decision had no relevance
to the fixing of a reasonable period for works to be completed. The production of the
expert’s decision could be delayed for reasons unconnected with the works: for example, if
the expert fell ill, or if his decision was set aside and a fresh decision had to be issued. There
was no commercial reason not to fix a date in the past.
Decision: Interpretation of Deferred Long Stop Date
[20]       The schedule to the missives could undoubtedly have been drafted with greater care
and clarity. The number of obvious cross-referencing and other errors in it does not inspire
confidence that it can be read literally as expressing the parties’ common intention. I bear in
mind, however, the well-known guidance on contractual interpretation provided by
Lord Clarke in Rainy Sky SA v Kookmin Bank [2011] 1 WLR 2900 at paragraph 21:
“The language used by the parties will often have more than one potential meaning.
I would accept the submission made on behalf of the appellants that the exercise of
construction is essentially one unitary exercise in which the court must consider the
language used and ascertain what a reasonable person, that is a person who has all
the background knowledge which would reasonably have been available to the
parties in the situation in which they were at the time of the contract, would have
understood the parties to have meant. In doing so, the court must have regard to all
the relevant surrounding circumstances. If there are two possible constructions, the
court is entitled to prefer the construction which is consistent with business common
sense and to reject the other.”
I bear in mind also the warning given by Lord Neuberger in Arnold v Britton [2015] AC 1619
at paragraphs 19 and 20:
Page 12 ⇓
12
“19. The third point I should mention is that commercial common sense is not to
be invoked retrospectively. The mere fact that a contractual arrangement, if
interpreted according to its natural language, has worked out badly, or even
disastrously, for one of the parties is not a reason for departing from the
natural language. Commercial common sense is only relevant to the extent of
how matters would or could have been perceived by the parties, or by
reasonable people in the position of the parties, as at the date that the contract
was made…
20. Fourthly, while commercial common sense is a very important factor to take
into account when interpreting a contract, a court should be very slow to
reject the natural meaning of a provision as correct simply because it appears
to be a very imprudent term for one of the parties to have agreed, even
ignoring the benefit of wisdom of hindsight. The purpose of interpretation is
to identify what the parties have agreed, not what the court thinks that they
should have agreed…”
[21]       In reaching a view on what the reasonable person described by Lord Clarke would
have understood the parties to these missives to have meant, I take as my starting point the
significance and meaning attributed therein to the Long Stop Date, leaving aside for the
moment any deferrals or extensions of time. In agreement with parties’ submissions, it
seems to me to be reasonably clear from the definition in paragraph 1.6 that there were, at
the time when the contract was entered into, two Long Stop Dates: one in respect of Priority
Works and one in respect of other works. Those were very important dates: in terms of
paragraph 5, they determined which of the parties was to become entitled to that part of the
retention referable to one or other category of works. If all of the items in a Package were
timeously completed, the retention was released to the defender; if not, it was released to the
pursuer. The operation of paragraph 5 in the context of two Long Stop Dates is, however,
rather obscure. Paragraphs 5.2 and 5.3 suggest that the whole of the Sub-Total for each
Package was to be released at the same time to the defender or the pursuer (as the case may
be) regardless of the division within the Package into Priority Works and other works. On
the other hand, paragraph 5.1 refers to the defender’s right to complete “the relevant
Remedial Works” ceasing on “the relevant Long Stop Date”, suggesting that the parties’
Page 13 ⇓
13
entitlements in respect of Priority Works and other works had to be considered separately.
This apparent conflict can be removed if one reads the word “relevant” into paragraphs 5.2
and 5.3, so that for example, paragraph 5.3 is read as applying “where all of the relevant
items in a Package of Remedial Works are not completed by the Seller by the relevant Long
Stop Date”.
[22]       On this reading, the defender’s payment entitlement would have been as follows:
On completion of a particular Priority Works item before the Priority Works
Long Stop Date (initially 5 November 2012), 50% of the retention in respect of
that item;
On completion of all of the Priority Works items in a Package before
5 November 2012, the balance of the retention in respect of those works; and
On completion of all other items in a Package before the non-priority works
Long Stop Date (5 January 2014), the retention in respect of those works.
Failure by the defender to complete all of the Priority Works in a Package prior to
5 November 2012 would have entitled the pursuer to receipt of the balance of the retention
in respect of those works, but not the retention in respect of non-priority works in that
Package. Failure by the defender to complete the non-priority works by 5 January 2014
would have entitled the pursuer to receipt of the balance of the retention in respect of those
works. It might be thought that there is something curious about the defender being entitled
to complete and receive the retention in respect of non-priority items in a Package after
having failed to complete the Priority Works in that Package; it seems to me, however, that
that is what was agreed.
[23]       Interpretation becomes more complicated when one takes into account the various
provisions allowing deferral or extension of time. Dealing firstly with the definition of
Page 14 ⇓
14
“Long Stop Date” in paragraph 1.6, I reject the pursuer’s submission that this envisaged a
possible increase in the number of Long Stop Dates up to a maximum of 23. In my opinion
the definition provides no support for allocating a Long Stop Date to a particular item of
works. I agree with the submission on behalf of the defender that it accords with
commercial common sense to read the words “a reasonable period or periods” as allowing
for more than one extension of time in respect of the same category of works (ie Priority
Works or other works). The reference to “the works in question” is similarly a reference to
one or other of those categories. My principal reason for preferring this interpretation is that
it preserves intact the system of payment entitlements described above, which depended
upon there being a specific date at which to ascertain whether or not all of the Priority
Works or other works (as the case might be) in a Package had been completed. If there were
to be several Long Stop Dates for completion of Priority Works and/or other works, the
payment system would become unworkable.
[24]       The foregoing interpretation is also consistent with the provisions of paragraph 3.11
which extended the Long Stop Date where court or arbitration proceedings were continuing
in respect of any Potentially Service Chargeable Items. Although references in
paragraph 3.11 to “the relevant item of Remedial Works” and “the relevant works” are
clearly to individual items of Remedial Works, the final sentence provided for extension of
“the Long Stop Date” and did not make provision for extension only in respect of an
individual item. Again this would have allowed the scheme for release of the retention to
remain intact and to operate as parties had planned. I note in passing that this interpretation
is also consistent with paragraph 3.12.1 which dealt with extension of the Long Stop Date
because of delay arising from force majeure or the act or default of the pursuer.
Page 15 ⇓
15
[25]       My finding that, on a proper construction of the missives, there could only ever be
two Long Stop Dates does not lead inexorably to a conclusion that there were only two
Deferred Long Stop Dates. That, however, is the view that I have reached. Turning next to
paragraph 5.3, which introduced the expression “the Cut-Off Date”, it is notable that this is
defined as the Long Stop Date “or, such later date identified in paragraphs 3.11 or [5.2]
above”. If, as I have found, paragraph 3.11 provided for extension of each Long Stop Date to
a single later date, it is consistent to construe the reference to a later date identified in
paragraph 5.2 in the same way, ie to a single Deferred Long Stop Date in respect of each of
the two categories of works. If there could have been up to 23 Deferred Long Stop Dates,
there could equally have been 23 Cut-Off Dates, and the same difficulty would arise in
fixing the date at which it had to be ascertained whether or not all of the items (in one
category of Remedial Works or the other) in a Package had been completed.
[26]       Against that background, I turn to paragraph 5.2.1 itself. I acknowledge that the
expressions “any Remedial Works” and “those particular works” are capable of supporting
the pursuer’s construction, ie that it is necessary to consider each item individually. They
are also, however, in my view, capable of referring to Remedial Works or works within one
or other of the two categories. That would be consistent (i) with the references in
paragraph 5.1 to “relevant” Remedial Works, and (ii) with the use of the singular “such later
date” in paragraph 5.3. The same would apply to the expressions “those works” and “those
Remedial Works” in the last sentence of paragraph 5.2.1: properly construed, that sentence
provided that if one or other category of Remedial Works (ie Priority Works or other works)
had not been completed by the relevant Deferred Long Stop Date, then the defender’s
entitlement to complete that category of Remedial Works would cease.
Page 16 ⇓
16
[27]       It is worth noting that neither paragraph 5.2.1 nor the definition of Deferred Long
Stop Date in paragraph 1.1 made any direct reference to Packages. Read together, they
provided for agreement or determination of a reasonable period of time after each of the
two Long Stop Dates for the whole of the Remedial Works in each category to be completed.
That left open the possibility that the works in some but not all of the Packages would be
timeously completed, as regards one or other category or both, but it also gave the defender
the opportunity to programme works with a view to avoiding missing either deferred
deadline.
[28]       I turn now to the question whether the Deferred Long Stop Date for either category
of works could be determined to be a date in the past. On the face of it, the language of
paragraph 1.1 suggests not: the definition referred to the period of time after the Long Stop
Date agreed or determined to be “reasonable to permit the remainder of those works which
have been started to be completed”. It appears to have been looking forward to completion,
and not backward to a period that would have been reasonable, viewed as at the Long Stop
Date, to achieve completion of the works. Paragraph 5.2.1 was, similarly, in prospective
terms, stating that the defender’s entitlement to carry out works “shall continue” until the
Deferred Long Stop Date, as opposed to, for example, stating that that entitlement shall have
continued until that date. I agree with the submission on behalf of the defender that the
primary purpose of providing for a Deferred Long Stop Date was to try to ensure that works
on which the defender had made a substantial start at the Long Stop Date could be
programmed to completion within a reasonable time, rather than, as the pursuer submitted,
to provide a detailed mechanism for distributing the retention in the event of failure by the
defender timeously to complete all 23 items.
Page 17 ⇓
17
[29]       It seems to me to be implicit in the definition of Deferred Long Stop Date that the
dates agreed or determined would be such as to allow a reasonable opportunity to complete
the category of works in question. That may indicate that at the time of the contract the
parties contemplated that any agreement or expert determination as to a Deferred Long Stop
Date would take place before, or perhaps shortly after, the corresponding Long Stop Date.
But, as senior counsel for the pursuer pointed out, that was not necessarily the case. If the
matter required to be referred to an expert for determination, that could lead to significant
delay if, for example, the expert was unable to deliver his determination due to illness or
death, and another expert had to be chosen, or if the expert’s determination were to be set
aside by the court so that another determination had to be given. Those considerations, it
was submitted, indicated strongly that the parties had envisaged that one or more of the
periods determined by the expert could have come to an end prior to the date of his
determination.
[30]       In my opinion the difficulties described by the pursuer arise only if one begins by
assuming that the reasonable period for completion of works must start at the Long Stop
Date. But that assumption is not necessarily justified by the wording of the definition. In
particular, the words “such period of time after the Long Stop Date” do not necessarily
mean “such period of time beginning on the Long Stop Date” but could also mean “such
period of time after (but not before) the Long Stop Date”. I consider that the latter
interpretation accords best with the prospective language of the remainder of the definition
and of paragraph 5.2.1, and with commercial common sense. It follows that, in my opinion,
the parties provided in the contract for the expert’s assessment of a reasonable period to be
made looking forward at the time of the determination. Although that might, in the
circumstances suggested by the pursuer, result in a very considerable time elapsing before
Page 18 ⇓
18
the Deferred Long Stop Date is reached, that in my opinion is what the parties agreed by the
terms which they used.
Disposal: Independent Expert’s Determination
[31]       For these reasons, I hold that the independent expert erred in law in fixing separate
Deferred Long Stop Dates for each of the 23 items. In that regard, he failed to answer the
question that was referred to him for determination. The consequences would appear to be
that his decision must be reduced, and that the pursuer is not entitled to the remedies it
seeks in the present action based upon the determination. However, as agreed at the
hearing, I shall put the case out by order to hear parties’ submissions on further procedure.
The Costs Issue
[32]       Paragraph 4.7 of part 10 of the schedule provided as follows:
“The reasonable and proper costs of the Purchaser in employing (i) the Purchaser’s
Representative; and (ii) any legal or other appropriate professionals in discharging
its responsibilities under this Part of the Schedule shall be borne by the Seller, and
where not reimbursed directly, may be deducted by the Purchaser from any sums to
be released to the Seller under this Part of the Schedule…”
The pursuer was, however, to be liable for its own costs in connection with (i) work done in
connection with the drafting and negotiation of the missives (other than a sum of £33,000
which the defender agreed to contribute); and (ii) any dispute (where the costs would be in
the award of the independent expert). The reference in paragraph 4.7 to the “Purchaser’s
Representative” was to a person whom the pursuer was entitled to appoint to act on its
behalf for the purposes of part 10 of the schedule. In the event of such appointment and
intimation thereof to the defender, the defender was authorised to deal with the
representative as the pursuer’s agent. The pursuer and the Purchaser’s Representative were
Page 19 ⇓
19
entitled to monitor the carrying out of Remedial Works and to attend all on-site meetings,
but not to issue instructions directly to the contractor or the professional team.
[33]       The pursuer avers that it has incurred costs of some £565,000 to its legal advisers in
discharging its responsibilities under part 10 of the schedule. A table, together with
supporting invoices and time sheets, has been lodged to explain how this sum is calculated.
The defender accepts its obligation in principle, but avers that many of the costs claimed do
not relate to discharging responsibilities and are accordingly not recoverable from it. The
defender further avers that it has sought to agree with the pursuer a method of identifying
work that does or does not fall within paragraph 4.7, and that the claim is premature.
[34]       In its submissions for the purposes of the debate, the defender set out what it
considered to be the responsibilities of the pursuer under part 10 of the schedule, as follows:
release of the retention from the joint account (paragraph 2.3);
responding to requests from the defender not to carry out any Remedial
Works and forfeiting the relevant retention (paragraph 3.1.2);
approving any inspection, testing, investigations or measurements in order to
precisely define the scope of the Remedial Works (paragraph 3.2);
approving any contractor other than the original design and build contractor
(paragraph 3.4);
agreeing a method statement and programme for any Remedial Works
(paragraph 3.8.1);
entering into a name borrowing agreement (paragraph 3.12);
inspecting any completed Remedial Works and giving reasons where it was
considered that those works were not complete (paragraph 4.4); and
Page 20 ⇓
20
certain obligations in relation to a disposal by the pursuer of its interest in the
property prior to completion of the Remedial Works (paragraph 6).
Many of the narrative entries in the invoices, it was submitted, demonstrated that the
defender was claiming costs that did not relate to the above “responsibilities”. In particular,
many related to costs incurred to the pursuer’s legal and technical representatives in
“looking over the shoulder” of the defender and its legal and technical representatives for
negotiating acceptable remedial works proposals from the original design and build
contractor. These were not recoverable. Paragraph 3.2 expressly provided for the benefit of
any report to be relied on by both the defender and the pursuer. All of the technical experts
instructed by the defender had provided duty of care letters in favour of the pursuer in
connection with their services. In any event, the claims required to be vouched before
payment, and the defender remained willing to discuss which work did or did not fall
within paragraph 4.7.
[35]       On behalf of the pursuer it was submitted that paragraph 4.7 clearly contemplated
that the pursuer would employ its own advisers, including legal advisers. It was not
obliged to rely upon another person’s report. The range of recoverable costs was wide: it
covered, for example, attending meetings on behalf of the pursuer. Paragraph 4.7 should be
read as covering whatever the schedule anticipated that the pursuer would have to do, or
might do. The claim was not irrelevant.
[36]       There are obviously matters in relation to the pursuer’s claim that cannot be resolved
without proof. At this stage, the best the court can do is to provide guidance as to the
proper interpretation of paragraph 4.7, in order that parties may apply that guidance in
identifying which of the costs claimed by the pursuer are recoverable from the defender. If
Page 21 ⇓
21
the guidance is not sufficient to resolve it, the issue will have to come back to the court for
proof before answer.
Decision: Costs Issue
[37]       Despite the semi-colon that appears after the words “the Purchaser’s Representative”
in paragraph 4.7, I read the qualifying words “in discharging its responsibilities under this
Part of the Schedule” as applying both to the Purchaser’s Representative and to “any legal or
other appropriate professionals”. This seems, however, to be largely immaterial for present
purposes because the claim is made for costs incurred to the pursuer’s legal advisers in the
capacity of legal professionals and not as the Purchaser’s Representative. In my opinion,
content has to be given to the phrase “in discharging its responsibilities” under part 10. The
insertion of this qualification indicates that it was not intended by the parties that the
pursuer should be entitled to recover all of its legal expenses in connection with the
retention and Remedial Works. While it is apparent that the pursuer would be likely to
require to instruct its own legal advisers with regard to the carrying out of the Remedial
Works, I do not accept that its entitlement under paragraph 4.7 is wide enough to cover the
cost of everything that those legal advisers would or might do in order to advance or protect
the pursuer’s interests. Implicit in the phrase “discharging its responsibilities” is a
requirement that these be responsibilities to the other party to the contract, and not simply
furtherance of the pursuer’s own interests. The right of recovery of costs incurred to the
pursuer’s legal professionals is accordingly, in my opinion, restricted in the manner
suggested by the defender.
[38]       As regards identification of the pursuer’s responsibilities, I agree that the cost of all
of the items in the defender’s list (above) would be included. To that list of responsibilities I
Page 22 ⇓
22
would add permitting the defender and its contractors a non-exclusive licence, in terms of
paragraph 3.3, to enter and remain upon the property for the purpose of carrying out the
Remedial Works, inspections etc. There may be others that I have not noticed; I suggest that
this be the subject of further discussion between parties in the light of the views that I have
expressed.
Disposal
[39]       As already mentioned, I shall put the case out by order to hear submissions on
further procedure.



BAILII: Copyright Policy | Disclaimers | Privacy Policy | Feedback | Donate to BAILII
URL: http://www.bailii.org/scot/cases/ScotCS/2017/[2017]_CSOH_152.html