[New search]
[Context
]
[View without highlighting]
[Printable PDF version]
[Help]
FIRST DIVISION, INNER HOUSE, COURT OF SESSION
[2021] CSIH 50
CA143/19
Lord President
Lord Menzies
Lord Woolman
OPINION OF THE COURT
delivered by LORD WOOLMAN
in the reclaiming motion by
Pursuers and Reclaimers
against
Defenders and Respondents
Pursuers and Reclaimers: Moynhian QC; Burness Paull LLP
Defenders and Respondents: Walker QC; CMS Cameron McKenna Nabarro Olswang LLP
5 October 2021
Introduction
[1]
In 2016 Aberdeen Harbour Board embarked on the construction of a new harbour at
Nigg Bay. It employed
Dragados
as the main contractor on this major expansion project. In
2
[2]
The terms of both the main contract (20 December 2016) and the subcontract
(16 March 2018) were based on the third revision of the New Engineering Contract
("NEC
3
").
[3]
During the course of the subcontract,
Dragados
transferred about one third of the
dredging to two other companies. Later it informed
Van
Oord
that it proposed to reduce the
sum payable for
Van
Oord's
remaining work under the "compensation event" provisions of
NEC
3
.
[4]
The proposed reduction was a significant one. The bill of quantities specified £7.48
per cubic metre (m
3
) as the rate for dredging.
Dragados
proposed to reduce it, in June 2019,
to £5.82m
3
, a 22% reduction, and further in September 2019 to £3.80m
3
, a 49.2% reduction.
[5]
Van
Oord
contested the reduction on the basis it was invalid, as
Dragados
had
breached the subcontract. It sought payment at the original bill rate.
[6]
The commercial judge heard a debate at first instance. He held that the transfer of
work by
Dragados
constituted a breach of the subcontract. He also concluded, however,
that
Dragados
was entitled to reduce the bill rate payable to
Van
Oord
for the remaining
works. His decision largely mirrored the outcome of earlier adjudications, which had found
[7]
Breach is now accepted. So the question for determination is this. Was
Dragados
entitled to reduce the sums payable to
Van
Oord?
The answer turns on the proper
construction of NEC
3
.
Background
[8]
Van
Oord
undertook to dredge an estimated 2,150,000m
3
of material to create the
3
new harbour. It also agreed to carry out
various
other works, including caisson filling. The
total
value
of the subcontract was about £26.4m.
[9]
In its tender
Van
Oord
inserted a `blended' rate for the dredging. That rate averaged
out the cost of easier and more difficult works.
Van
Oord
selected the rate on the footing
that it would undertake all the dredging work.
[10]
Van
Oord
began dredging on 5 May 2018. Within a short period,
Dragados
began
issuing notices to omit certain dredging, which it transferred under the following
contractual arrangements:
Date (2018)
Company
15 May
WASA Dredging UK
Ltd
400,000m
3
14 December
Canlemar SL
300,000m
3
The formal subcontract with Canlemar was preceded by a letter of intent dated 13 August
2018.
[11]
Van
Oord
did not learn about the transfers for some time. It raised this action in
September 2019. At that stage it sought
various
orders, including interim interdict against
further transfers of dredging work. Its application was unsuccessful. The commercial judge
concluded that the balance of convenience tipped in favour of
Dragados,
because it had
entered into binding obligations with WASA and Canlemar.
[12]
Dragados
terminated the subcontract on 6 March 2020. The issue now concerns the
correct
valuation
of the dredging works in the termination account.
Van
Oord
seeks
(i) declarator that
Dragados
was not entitled to reduce the sum payable to it for work done
consequent upon the disputed instructions, and (ii) payment of a sum based on the original
bill rate.
4
[13]
The parties advance
various
claims and counterclaims. Some of the disputes can only
be resolved by means of evidence.
[14]
is seeking to manipulate the contract in its favour. Had
Van
Oord
known that it would be
left with a disproportionately higher share of the more difficult work, it would have
increased the dredging bill rate in its tender.
Van
Oord
claims that
Dragados:
(a) insisted on
a blended rate in the tender; (b) transferred more of the easier work to the other two
companies; and (c) did so to avoid having to pay standby charges (at least in the case of
WASA).
[15]
Dragados
argues that there has been no manipulation on its part. It maintains that
NEC
3
provides a blueprint for the circumstances that have arisen. It also maintains that the
recalculation yields a fair result to
Van
Oord,
which would otherwise receive a windfall
benefit. With regard to factual matters,
Dragados
claims that
Van
Oord:
(a) showed poor
productivity; (b) would have made a loss on the transferred work; (c) facilitated the transfer
of works to WASA; and (d) would be left neither better nor worse off by the NEC
3
compensation event mechanisms.
NEC
3
[16]
Like all standard form contracts, NEC
3
consists of a series of interlocking terms.
Relevant Terms
[17]
The following clauses are at the centre of the dispute:
Clause 10.1:
"The Contractor and the Subcontractor shall act as stated in this subcontract and in a
spirit of mutual trust and co-operation."
5
Clause 14.3:
"The Contractor may give an instruction to the Subcontractor which changes the
Subcontract Works Information or a Key Date. The Contractor may, in the event that
a corresponding instruction is issued by the Project Manager under clause 14.3 of the
Main Contract only, also give an instruction to omit a) any Provisional Sum and/or b)
any other work, even if it is intended that such work will be executed by Others. The
Subcontractor has no claim for loss of revenue, loss of opportunity, loss of any
contract, loss of profit or for any indirect loss or damage against the Contractor in
relation thereto."
Clause 27.3:
"The Subcontractor obeys an instruction which is in accordance with this subcontract
and is given to him by the Contractor."
Clause 60.1:
"The following are compensation events ... (18) A breach of subcontract by the
Contractor which is not one of the other compensation events in this subcontract or
any act of prevention."
Clause 60.4:
"A difference between the final total quantity of work done and the quantity stated
for an item in the Bill of Quantities is a compensation event if
the difference does not result from a change to the Subcontract Works
Information,
the difference causes the Defined Cost per unit of quantity to change and
the rate in the Bill of Quantities of the item multiplied by the final total
quantity of work done is more than 0.5% of the total of the Prices at the
Subcontract Date.
If the Defined Cost per unit of quantity is reduced, the affected rate is reduced."
Clause 60.6:
"The Contractor corrects mistakes in the Bill of Quantities which are departures from
the rules for item descriptions and for division of the work into items in the method
of measurement or are due to ambiguities or inconsistencies. Each such correction is
a compensation event which may lead to reduced Prices."
6
Clause 63.2:
"If the effect of a compensation event is to reduce the total Defined Cost, the Prices
are not reduced except as stated in this subcontract."
Clause 63.4:
"The rights of the Subcontractor to changes to the Prices and the Subcontract
Completion Date are its only rights in respect of a compensation event."
Clause 63.10:
"If the effect of a compensation event is to reduce the total Defined Cost and the
event is
a change to the Subcontract Works Information or
a correction of an assumption stated by the Contractor for assessing an earlier
compensation event,
the Prices are reduced."
[18]
Clause 10.1 provides a useful starting point. The commercial judge concluded that
this term did not add much. He instead based his decision on the cluster of clauses that
regulate compensation events. Mr Walker invited us to take the same approach.
[19]
We decline to do so. In our
view
clause 10.1 is not merely an avowal of aspiration.
Instead it reflects and reinforces the general principle of good faith in contract: McBryde, The
Law of Contract in Scotland 3rd edition paras 17-23 to 17-34.
[20]
In particular, clause 10.1 aligns with three specific propositions:
(i).
A contracting party "will not in normal circumstances be entitled to take
advantage of his own breach as against the other party": Alghussein
Establishment
v
Eton College [1988] 1 WLR 587, 591D-E, per Lord Jauncey.
7
(ii).
A subcontractor is not obliged to obey an instruction issued in breach of
contract: Thorn
v
The Mayor and Commonalty of London (1876) 1 App. Cas. 120,
per Lord Cairns (LC) at 127-128.
(iii).
Clear language is required to place one contracting party completely at the
mercy of the other: Parkinson (Sir Lindsay) & Co. Ltd
v
Commissioners of His
Majesty's Works and Public Buildings [1949] 2 KB 632, 662 per Asquith LJ.
[21]
Mr Moynihan places special emphasis on the first proposition, although accepting
that he did not cite it to the commercial judge.
[22]
Lord Jauncey's statement embodies the doctrine of mutuality. A party cannot
enforce a contractual stipulation in its favour, if it is the counterpart of another obligation
which it has breached: see Macari
v
Celtic Football and Athletic Co Ltd 1999 SC 628 at 640G-
641D, per the Lord President (Rodger), and Bank of East Asia
v
Scottish Enterprise 1997 SLT
1213, per Lord Jauncey at 1216L-1217K.
[23]
We conclude that clauses 10.1 and 63.10 are counterparts. Unless
Dragados
fulfils its
duty to act "in a spirit of mutual trust and co-operation", it cannot seek a reduction in the
Prices. Accordingly,
Van
Oord
has pled a relevant case to go to proof. Evidence can be led
to evaluate
Dragados'
conduct. Did it act in a spirit of mutual trust and co-operation? Or
did it act in a contrary manner?
Did the instructions lead to a reduction in the dredging rate?
[24]
Each breach by
Dragados
constituted a compensation event. That is because of the
"catch all" wording of clause 60.1(18).
[25]
NEC
3
contains a complex formula to assess the
value
of a compensation event.
Happily it is not necessary to carry out the exercise here. The parties agree that there is a
8
reduction in the Defined Cost. They disagree, however, on whether there is also a reduction
in the Prices and the bill rate payable for the remaining work.
[26]
By way of clearing the ground, breach of contract is not such an occasion
(clauses 60.4, 60.6 and 63.10). Accordingly, the breach of contract by
Dragados
does not give
rise to a reduction in the Prices, even if its effect is to reduce the total Defined Cost.
[27]
The commercial judge held that clause 63.10 governed the situation. He held that the
sole remedy available to
Van
Oord
was to have that change assessed in accordance with the
compensation event pricing mechanism (clause 63.4).
[28]
Mr Walker urged us to accept that approach, which he amplified as follows.
Recalculation arises because of
Van
Oord's
pricing strategy and its failure to achieve its
productivity rates. It would have made a loss if it had completed the omitted work.
Payment at the original bill rate would result in it receiving a windfall benefit. The aim of
the recalculation is to place both parties in the same position as they would have been in if
the breach had not occurred. Neither would be better or worse off. So
Dragados
gains no
advantage by this procedure.
[29]
We reject that argument. NEC
3
states that all compensation events are
valued
in the
same way (clause 63.1), but continues that if
"the effect of a compensation event is to reduce the total Defined Cost, the Prices are
not reduced except as stated in this subcontract" (clause 63.2).
We conclude that, properly construed, clause 63.10 applies only to a lawful change. It
excludes instructions issued in breach of contract. They are invalid, because they are not
given "in accordance with this subcontract" (see clauses 14.3 and 27.3). The natural
synonym for "in accordance with" is "consistent with". A breach is plainly inconsistent
with the contract.
9
[30]
We add these points in support of our interpretation. First, it means that all breaches
are treated equally. None produces a reduction in the Prices. Second, it avoids the
suggestion that
Van
Oord
was bound to obey a "breach instruction". That cannot be right.
To take a fanciful example, it would have been under no obligation to build a hotel if
Dragados
had issued such an instruction. Third, the NEC
3
should not be charter for contract
breaking.
Conclusion
[31]
We shall recall the interlocutors of the commercial judge dated 7 October 2020, and
allow a proof before answer. We shall sustain
Van
Oord's
second plea in law to the extent of
excluding from probation those averments in Answers 14, 15 and 20 stating that
Dragados is
allowed to reduce the bill rate.
BAILII:
Copyright Policy |
Disclaimers |
Privacy Policy |
Feedback |
Donate to BAILII
URL: http://www.bailii.org/scot/cases/ScotCS/2021/2021_CSIH_50.html