![]() |
[Home] [Databases] [World Law] [Multidatabase Search] [Help] [Feedback] [DONATE] | |||||||||
England and Wales High Court (Technology and Construction Court) Decisions |
||||||||||
|
THE FUTURE OF BAILII DEPENDS ON USERS LIKE YOU
If you want to be able to use BAILII in the future, please consider making a donation to celebrate BAILII's 25 years of providing free access to law.
Your donation, no matter the size, will help BAILII maintain the legal databases that you and many other users rely on. If every visitor this month gives just £5, it will have a significant impact on BAILII's ability to continue providing this vital service.
| ||||||||||
|
You are here: BAILII >> Databases >> England and Wales High Court (Technology and Construction Court) Decisions >> Hackney Empire Ltd v Aviva Insurance UK Ltd [2011] EWHC 2378 (TCC) (21 September 2011) URL: https://www.bailii.org/ew/cases/EWHC/TCC/2011/2378.html Cite as: [2011] BLR 726, 138 Con LR 165, [2011] EWHC 2378 (TCC) |
||||||||||
[New search]
[Context
]
[View without highlighting]
[Printable RTF version]
[Help]
QUEEN'S BENCH DIVISION
TECHNOLOGY AND CONSTRUCTION COURT
Strand, London, WC2A 2LL |
||
B e f o r e :
____________________
HACKNEY EMPIRE LIMITED |
Claimant |
|
| - and - |
||
AVIVA INSURANCE UK LIMITED(formerly trading as NORWICH UNION INSURANCE LIMITED) |
Defendant |
____________________
Mr Richard Wilmot-Smith QC and Miss Alexandra Bodnar (instructed by HBJ Gateley Wareing LLP) for the Defendant
Hearing dates: 4th – 6th July 2011
____________________
VERSION
OF JUDGMENT
Crown Copyright ©
Mr Justice Edwards-Stuart:
Introduction
Hackney
Empire
Ltd
("HEL"), owns the
Hackney
Empire
Theatre in east London. In 2001 HEL decided to carry out extensive works of refurbishment to the theatre, a building of considerable architectural interest with many period features. The contractor was Sunley Turriff Construction
Ltd
("STC"). Unfortunately, the contractor fell into considerable delay and was unable to complete the work. On 2 July 2003 STC went into administration.
Aviva
Insurance
UK
Ltd
("
Aviva"),
together with STC, executed a bond in favour of HEL in the sum of £1,106,852. The bond secured the due performance of STC's obligations under the building contract for the refurbishment works.
Aviva
is liable under the bond and, if so, whether that liability extends to STC's failure to repay the £750,000 that was advanced on account of its claims that were never, in the end, substantiated. In addition to the advance of the £750,000, HEL also agreed to pay for certain off site materials for which it was not contractually bound to pay under the terms of the building contract.
Aviva
contends that the payment of the £750,000 and/or the payments in respect of off-site materials were the result of agreements between HEL and STC made with reference to the building contract but without the knowledge of
Aviva
in circumstances that were prejudicial to
Aviva.
The result, says
Aviva,
is that its liability under the bond was discharged. If it is wrong about this, its secondary case is that it cannot be liable for the default in respect of the £750,000 because that was not an obligation that came within the scope of its guarantee: in fact, it submits that its only liability would be in respect of HEL's accrued right to liquidated damages in the sum of £205,000.
Aviva
is liable under the bond because the arrangements by which HEL agreed to pay the £750,000 and for the off-site materials were
variations
to the building contract or acts of forbearance that were permitted under the terms of what is often called an "indulgence clause" in the bond.
The background
Events up to 16 December 2002
Aviva
(then called Norwich Union
Insurance
Ltd)
executed the bond in the sum of £1,106,852 in favour of HEL.
various
amendments.
(1) the refurbishment of the historic auditorium and foyer, which was known as "Matcham" (after the architect who designed the building);(2) works to the stage and backstage buildings - involving alterations, extension and new building - this was known as "Stage and Backstage"; and
(3) work to construct a new building in an adjacent public house, which belonged to HEL, to provide front of house space, access and service spaces - this was known as "Pepys".
(1) HEL should engage construction contract specialists to provide strategic advice to the Board and the project team (this advice was subsequently repeated in his letter to HEL dated 15 July 2002).(2) The architect's team should be expanded to include an architect or surveyor to deal with STC's claims.
(3) The architect's appointment should be extended to ensure that current team activities could continue through the extended construction period.
(4) The services of the Clerk of Works/Resident Architect should be extended through to completion.
views
by both sides. Mr Wolfe, STC's Managing Director, said that there were substantial matters in dispute with a
value
amounting to about £750,000, together with a further £500,000 in respect of work which STC said had been undervalued. It was noted at the meeting that arrangements for the payment of off-site materials were close to resolution and were subject to proper
insurances
and bonds being put in place.
varied
works had caused 10 weeks delay, and the document included a one page Delay Analysis Programme showing how the events impacted on STC's programme for the works.
views
as to the responsibility for the delays. The architect, Mr Ronalds, who gave evidence before me, thought that STC was incompetent and under-resourced and it is clear that the professional team took the
view
that STC was responsible for the lion's share of the delay. However, STC contended the contrary and continued to submit numerous claims for extensions of time and associated loss and expense. With one or two exceptions, these claims were never substantiated and STC did not provide the particulars in support of its claims that were required under the terms of the building contract. One of STC's particular complaints was that the project was meant to be fully designed, yet in the course of carrying out the works they received over 1,000 instructions.
value
was £15.25 million).
visited
the site on 22 October 2002, during which he was briefed by both parties. At the
visit
he offered to arbitrate between the parties and to that end he held a meeting with the parties on 13 November 2002, which was intended as a form of mediation. Lord Sugar proposed that HEL should make a payment on account to STC in respect of its claims in a number of instalments. After further discussions between the parties in November and December 2002, HEL offered to pay £1 million to STC in three instalments. However, STC wanted the full amount paid at once. It was accepted on both sides that the sum or sums advanced would be a payment on account in respect of STC's claims pending the provision of proper particulars.
Aviva,
submits that the circumstances in which the first payment of £500,000 was paid in December are in themselves sufficient to discharge
Aviva
from liability under the bond. It is therefore necessary to establish the arrangements or agreement under or by which the first payment was made.
What was agreed on 16 December 2002
"TR asked for programme. Said HET [HEL] insist no programme - no payment.
C Kent/LM Sanders [STC] said programme will be provided on 18.12.2."
"In the meantime, I would reiterate that we are continuing to progress the works to achieve Practical Completion on or before 31 May 2003, in line with the 'spirit' of our original agreement."
VAT,
on about 30 December 2002.
Events from 2003 onwards
value
of STC's claims. In a letter dated 2 January 2003 Mr Cameron Smith, of Boyden & Company, indicated that £1.8 million was a figure in the region of which a settlement might be achieved, although he warned that it was difficult to be precise in the absence of the claim details.
various
points in response to those raised by Mr Kent. The letter concluded by asking for confirmation that Mr Kent was content with these counterproposals. Mr Kent replied the following day, 19 February 2003, referring to 'The Agreement', suggesting further amendments and asking for Mr Thomsett's comments.
VAT.
This cheque appears to have been sent by HEL without waiting for confirmation from STC that the terms of HEL's first letter were agreed.
Hackney
siege (an incident when an armed man occupied a building in Graham Road,
very
close to the
Hackney
Empire
Theatre, between 26 December 2002 and 10 January 2003 causing much disruption to local activity). The letter concluded as follows:
"In the meantime, I assume that you will be able to formally extend the date of the Employer/Contractor 'Agreement', by three weeks."
view,
both payments were made on the terms of the bare oral agreement that I have set out in paragraph 30 above.
very
technical, including the
Hackney
Empire
project. He said that in his opinion STC was not equipped to take on projects of this type and had been over ambitious in doing so.
version
of the Side Agreement of the same date, made it clear that the extension of the target date for completion was not to be construed as an extension of time.
validity
or otherwise of the amendment to the Side Agreement is of no relevance to the issues that I have to decide. In any event,
Aviva
no longer relies on it.
Hackney
siege.
Aviva
and gives rise to one of the agreed issues.
Aviva,
replied to HEL's letter denying that
Aviva
was liable under the bond. They took three points:
(1) The employment of STC had been determined under clause 27.3.4, which required that an account be taken under clause 27.6.5 of the Conditions. It was said that this account was not due until the works had been completed and the subsequent expiry of the Defects Liability Period. Since insolvency, by itself, was not a breach of contract, any claim under the bond was premature and could only be made following the expiry of the Defects Liability Period.(2) The guarantee under the bond was in favour of
Hackney
![]()
Empire
Theatre, not
Hackney
![]()
Empire
![]()
Ltd.
Accordingly HEL had no claim under the bond.
(3) Without prejudice to the last point, Tozer Gallagher relied on the making of the Side Agreement without the knowledge of
Aviva.
It contended that this was prejudicial to
Aviva
and that it was consequently under no liability under the bond.
The terms of the bond
Aviva
as Surety:
"are held and firmly bound unto [HEL] …in the sum of £1,106,852… for the payment of which sum the Contractor and Surety bind themselves their successors and assigns jointly and severally by these presents."
The conditions of the bond were that if:
"(a) the contractor shall subject to Condition (c) hereof duly perform and observe all the terms provisions conditions and stipulations of [the contract between STC and HEL for the construction and completion of works] on the Contractor's part to be performed and observed according to the true purport intent and meaning thereof or if
(b) on default by the Contractor the Surety "shall satisfy and discharge the damages sustained by the Employer thereby up to the amount of the above-written Bond or if
(c) the Architect defined in the said Contract shall pursuant to the provisions thereof issue a Certificate of Practical Completion then upon the date stated therein (hereinafter called "the Relevant Date")
this obligation shall be null andvoid
but otherwise shall remain in full force and effect but no alteration in the terms of the said Contract made by agreement between the Employer and the Contractor or in the extent or nature of the Works to be constructed and completed thereunder and no allowance of time by the Employer or the Architect under the said Contract nor any forbearance or forgiveness in or in respect of any matter or thing concerning the said Contract on the part of the Employer or the said Architect shall in any way release the Surety from any liability under the above-written Bond."
I shall refer to the last eight lines of this bond as "the indulgence clause".
Aviva
quite properly took no point that HEL was not a party to the bond. Indeed, it pleaded that the bond was in favour of HEL.
The terms of the building contract
Clause 25.2.1.1: If and whenever it becomes reasonably apparent that the progress of the Works is being or is likely to be delayed [STC] shall forthwith give written notice to the Architect of the material circumstances including the cause or causes of the delay and identify in such notice any event which in [STC's] opinion is a Relevant Event.
Clause 25.4 defines "Relevant Event".
Clause 25.2.2: In respect of each and every Relevant Event identified in the notice ... [STC] shall, if practicable in such notice, or otherwise in writing as soon as possible after such notice:
.1 give particulars of the expected effects thereof; and
.2 estimate the extent, if any, of the expected delay in the completion of the Works beyond the Completion Date resulting therefrom whether or not concurrently with delay resulting from any other Relevant Event...
Clause 25.2.3: [STC] shall give such further written notices to the architect... as may be reasonably necessary or as the Architect may reasonably require for keeping up-to date the particulars and estimate referred to in clauses 25.2.2.1 and 25.2.2.2 including any material change in such particulars or estimate.
Clause 25.3.1: If, in the opinion of the Architect, upon receipt of any notice, particulars and estimate under clauses 25.2.1.1, 25.2.2 and 25.2.3.
.1 any of the events which are stated by [STC] to be the cause of the delay is a Relevant Event and
.2 the completion of the Works is likely to be delayed thereby beyond the Completion Date
the Architect shall in writing to [STC] give an extension of time by fixing such later date as the Completion Date as he then estimates to be fair and reasonable ...
. . .
If, in the opinion of the Architect, upon receipt of any such notice, particulars and estimate, it is not fair and reasonable to fix a later date as a new Completion Date, the Architect shall if reasonably practicable having regard to the sufficiency of the aforesaid notice, particulars and estimate so notify [STC] in writing not later than 12 weeks from receipt of the notice, particulars and estimate, or, where the period between receipt thereof and the Completion Date is less than 12 weeks, not later than the Completion Date.
Provided always that:
.1 [STC] shall use constantly his best endeavours to prevent delay in the progress of the Works, howsoever caused, and to prevent the completion of the Works being delayed or further delayed beyond the Completion Date;
.2 [STC] shall do all that may reasonably be required to the satisfaction of the Architect to proceed with the Works.
Clause 26.1: If [STC] makes written application to the Architect stating that he has incurred or is likely to incur direct loss and/or expense (of which [STC] may give his quantification) in the execution of this Contract for which he would not be reimbursed by a payment under any other provision in this Contract…because the regular progress of the Works or any part thereof has been or is likely to be materially affected by any one or more of the matters referred to in clause 26.2; and if and as soon as the Architect is of the opinion…that the regular progress of the Works or of any part thereof has been or is likely to be so materially affected as set out in the application of [STC] then the Architect from time to time thereafter shall ascertain, or shall instruct the Quantity Surveyor to ascertain, the amount of such loss and/or expense which has been or is being incurred by [STC]; provided always that:
.1 [STC's] application shall be made as soon as it has become, or should reasonably have become, apparent to him that the regular progress of the Works or of any part thereof has been or was likely to be affected as aforesaid; and
.2 [STC] shall in support of his application submit to the Architect upon request such information as should reasonably enable the architect to form an opinion as aforesaid; and
.3 [STC] shall submit to the Architect or to the Quantity Surveyor upon request such details of such loss and/or expense as are reasonably necessary for such ascertainment as aforesaid.
Clause 26.5: Any amount from time to time ascertained under clause 26 shall be added to the Contract Sum.
Clause 26.6: The provisions of clause 26 are without prejudice to any other rights and remedies which the Contractor may possess.
27.3.1 If [STC]…
being a company,
…under the Insolvency Act 1986 or any amendment or re-enactment thereof has an administrator … appointed then…
27.3.4 … [HEL] may at any time…by notice to [STC] determine the employment of [STC] under this Contract and such determination shall take effect on the date of receipt of such notice. …
27.5 Clauses 27.5.1 to 27.5.4 are only applicable where clause 27.3.4 applies.
27.5.1 From the date when, under clause 27.3.4, [HEL] could first give notice to determine the employment of [STC], [HEL], subject to clause 27.5.3 shall not be bound by any provisions of this Contract to make any further payment thereunder and [STC] shall not be bound to continue to carry out and complete the Works in compliance with clause 2.1.
27.5.2 Clause 27.5.1 shall apply until…
.2 [HEL] determines the employment of [STC] under this Contract in accordance with clause 27.3.4, in which case the provisions of clause 27.6 or clause 27.7 shall apply.
27.6 In the event of the determination of the employment of [STC] under clause … 27.3.4 … and so long as that employment has not been reinstated then:
.1 [HEL] may employ and pay other persons to carry out and complete the Works and to make good defects of the kind referred to in clause 17 or he or they may enter upon the site and the Works and use all temporary buildings, plant, tools, equipment and Site Materials, and may purchase all materials and goods necessary for the carrying out and completion of the Works and for the making good of defects as aforesaid…
.2 … [HEL] may pay any supplier or sub-contractor for any materials or goods delivered or works executed for the purposes of this Contract before or after the date of determination in so far as the price thereof has not already been paid by [STC]. Payments made under clause 27.6.2.2 may be deducted from any sum due or to become due to [STC] or may be recoverable from [STC] by [HEL] as a debt; …
.4 Upon the completion of the Works and the making good of defects as referred to in clause 27.6.1 (but subject, where relevant, to the exercise of the right under clause 17.2 and/or clause 17.3 of the Architect, with the consent of [HEL], not to require defects of the kind referred to in clause 17 to be made good) then within a reasonable time thereafter an account in respect of the matters referred to in clause 27.6.5 shall be set out either in a statement prepared by [HEL] or in a certificate issued by the Architect. …
27.8 The provisions of clauses 27.2 to 27.7 are without prejudice to any other rights and remedies which [HEL] might possess.
The Side Agreement
"The understanding set out in this letter relates to the JCT form agreement dated 5 March 2002 between [HEL] and [STC] ("the Agreement") [i.e. the Building Contract].
This letter sets out the basis upon which [HEL] will pay a sum on account to [STC] in respect ofvarious
claims. This sum is being paid to ensure that the Works are completed as soon as possible by [STC], in accordance with [STC's] obligations under the Agreement [i.e. the Building Contract], without the Works being delayed prior to the resolution of certain matters arising from the Agreement. It is also intended that this will avoid the necessity for such matters to be decided upon by the appropriate third party at this stage.
[HEL] and [STC] agree the following:
1. In the absence of details and substantiation against the Extension of Time notification/applications submitted by [STC] and backup and detail regarding the loss and expense or general claims for disturbance to the regular progress or disruption made by [STC] to date (together "the Claims"), [HEL] shall pay [STC] an "on account" sum of £1,000,000…("the Sum") (or as reduced in accordance with paragraph 3 below in relation to the third instalment) against the Claims subject to the terms and conditions set out in this letter.
2. Subject to the conditions in this letter being met by [STC], [HEL] shall pay [STC] the sum in the following instalments on account of any sums which are or become properly due to [STC] in respect of the Claims and any further claims [STC] may make pursuant to or in connection with the Agreement:
- First instalment of £500,000 to be paid on or before 31 December 2002.
- Second instalment of £250,000 to be paid on or before 28 February 2003.
- Third instalment of £250,000 to be paid on 2 June 2003 however, this third instalment shall only be paid if Practical Completion has been achieved by 31 May 2003 or by the Completion Date if, prior to 31 May 2003, the Completion Date has been formally extended in accordance with the Agreement to a date after 31 May 2003.
3. [STC] shall, in accordance with the Agreement, progress the works and use his best endeavours to achieve Practical Completion on or before 31 May 2003. [STC] shall issue a target programme to completion and estimated cashflow projection before 31 December 2002.
4. In addition to its obligations under the Agreement, [STC] shall attend meetings arranged by mutual agreement to discuss the Claims and provide details, substantiation and information in relation to them in accordance with the Agreement. These meetings are to be attended by [STC], Design Team and [HEL] as required with respective contractual roles maintained as per the Agreement.
5. [STC] and [HEL] shall not initiate any dispute resolution mechanism (including adjudication, arbitration and litigation) in respect of any claim related item, which arises prior to 31 May 2003 at any time before 31 May 2003. For the avoidance of doubt, any such claims may be brought but only after this date has passed.
6. Payments or deductions for Liquidated and Ascertained Damages due under Clause 24 of the Agreement will not be levied before 31 May 2003 and will not exceed £100,000…in total for any entitlement due for the period up to 31 May 2003. For the avoidance of doubt, [HEL's] entitlements under the Agreement in respect of Liquidated and Ascertained Damages after 31 May 2003 is not affected by the letter.
7. In the event that [STC] is in breach of any provision of this letter, any sum paid hereunder shall immediately be repayable and [STC] shall have no entitlement to any further instalment of the Sum which otherwise may have fallen due.
8. The terms of this letter are supplemental to the Agreement and, save to the extent that it has been expressly amended by this letter, the Agreement shall remain in full force and effect. In the event of a conflict between the terms of this letter and the terms of the Agreement, this letter shall prevail over the Agreement.
Nothing contained in this letter or any part of it shall be considered to be either an express or implied acceptance by [HEL] of the legitimacy of any claim put forward by [STC] under the Agreement or otherwise and [STC] will be required to demonstrate thevalidity
of any such claim in accordance with the terms of the Agreement. Nothing in this letter (including, for the avoidance of doubt, payment of the Sum) may be relied upon by either party as evidence of any such acceptance or as an instruction to
vary
the works or the manner in which they are to be performed."
The interaction between the Side Agreement and the building contract
view,
an agreement to make a payment on account in respect of loss and expense notified under clause 26 of the building contract does not conflict with the terms of the building contract because the Conditions are entirely silent on this: there is no contractual machinery for the making of payments on account in respect of claims. Further, I consider that the requirement for STC to attend meetings to discuss the claims and to provide details, substantiation and information in relation to them in accordance with the agreement was not in conflict with the terms of clause 26 of the building contract.
vary
(by
virtue
of clause 8 of the Site Agreement), the terms of the building contract. In my
view,
the Side Agreement is a freestanding agreement that is related to the building contract, but does not
vary
its terms - save in the two respects that I have mentioned.
Aviva
as the bondsman.
variation
that is of minimal consequence: neither party's right to initiate any dispute resolution process was excluded, it was only restricted for a period of 3 months or so prior to 31 May 2003. I did not understand Mr Wilmot-Smith to challenge this. Further, insofar as STC was concerned, any detriment caused by that limitation was wholly or significantly offset by the proposed advance on account of its claims.
variations
fall within the scope of the indulgence clause and so could not give
Aviva
the right to treat itself as discharged.
The issues
1. Whether or notAviva
is discharged from liability under the Bond arising from:
1.1 A payment of £500,000 made by HEL to STC on 31 December 2002;1.2 The execution of the Side Agreement of 26 February 2003;1.3 A later payment of £250,000 by HEL to STC pursuant to the Side Agreement; or
1.4 The amendments to the Side Agreement on or about 24 April 2003.
2. If
Aviva
is not discharged from liability under the bond, does its liability extend only to the payment of liquidated damages of £205,000 which had accrued due at the date of termination?
2.1 if not, for which if any of the matters set out at paragraph 39 of the Particulars of Claim isAviva
liable? (Quantification to be deferred to a potential quantum trial).
3. Whether or not HEL accepted a repudiatory breach of the Building Contract by STC so as to entitle HEL to claim sums from STC:
3.1 in excess of the liquidated damages accrued under the Building Contract prior to determination; and3.2 without the need to comply with clause 27.6.4.2 of the Building Contract's Conditions.4. 4.1 If HEL has not accepted a repudiatory breach of contract, whether or not a reasonable time for HEL to issue a statement or the Architect to issue a certificate under clause 27.6.4.2 has now expired?
4.2 If so, whether that deprives HEL of any entitlement it otherwise has or may have, in particular under clause 27.6.
5. If
Aviva
has not been discharged, what is its interest on the sums claimed by HEL?
Aviva.
Accordingly, the only issues that I have to address under issue 1 are issues 1.1 and 1.2. I did not understand this to be in dispute.
The witnesses and HEL's management of the project
Aviva
did not call any evidence. There were several ring binders containing copies of the relevant contemporaneous correspondence.
Q. You have 114?Hackney
![]()
Empire
Theatre, a letter from you to Mr Lanny Silverstone of Cawdrey Kaye Fireman and Taylor.
A. CKFT is the name they became, they shortened it.
Q. Yes. It is fair to say that he was not a construction specialist, is it not?
A. I do not know. He was the partner who we were put to, we were guided to.
Q. Did you look him up on the website to see what his areas of expertise were?
A. Not to my memory.
Q. Indeed, after you went to see him, he told you that if there was to be an adjudication he would have to avail himself of the services of a specialist construction counsel, did he not?
A. That sounds likely, yes.
Q. And there is no indication anywhere in any of the papers anybody has seen that Mr Lanny Silverstone is a specialist in dealing with contractors' claims like this. I would be right, would I not?
A. Yes, sir.
Q. How on earth did you alight upon this individual?
A. CKFT were a firm we had used for many other areas of our business. They --
Q. The advice you received was to get specialist construction advice. The man you instructed three months later was a man who was not equipped to give that; that would be right, would it not?
A. That would be right, and it is why we then in fact sought a different firm and specifically alighted upon Cameron McKenna.
view
that it was more likely to achieve its objectives through negotiation and, if necessary, some form of payment on account to STC, then by preparing a position in case it had to meet a referral to adjudication. By contrast, Mr Ronalds was a man who felt strongly that contractual procedures should be followed and that it was most unwise to engage in any form of dialogue outside the machinery of the contract. He was opposed in principle to making any payment on account to STC, and he made HEL aware of this
view.
However, in his witness statement he said that "I recognised then [December 2002] and recognise now that there was an exposure for HEL in respect of [STC's] claims". This evidence was not challenged.
view
did not prevail. Having paid £500,000 to STC at the end of December 2002 HEL found that little improvement resulted. By the end of February 2003, HEL had lost a further four weeks. So when HEL paid the second instalment on 26 February 2003 it knew that the rate of progress on site was not improving. The essence of Mr Thomsett's approach to the problem of dealing with a contractor that was persistently failing to perform is perhaps given by the following passage in his cross-examination:
Q. And because you had not got yourself ready to deal with any adjudication as you would have been had you taken the architect's advice of a year earlier, you felt it was better to give this failing contractor another quarter of a million pounds rather than operate the deal you thought you had on 20 December?A. That's with respect, a poor analysis, sir. The decision to pay the next 250 was simply that we felt obliged to do so to have any chance at all of having a building back within a reasonable timescale. That is the first point. The second is I go back to my, I am afraid, the place I retreat to often, which is that the Heritage Lottery Fund and Arts Council Lottery Fund monitors who played an extremely straight bat found this all amazingly stressful because a side agreement in itself was unusual and disturbed them and they felt
vulnerable,
the National Audit Office, etc, who were checking files. If we were to then do something which may be commercially the answer in retrospective -- actually I'm not even sure in retrospect that I agree with you but it's arguable that to not pay the 250 and to demand the £500,000 back at that point would have been a good decision, but it certainly didn't seem one at the time. We just were anxious to get as much work done as quickly as possible and the only way to motivate them was to continue with the agreement and that's how we felt. I think we were also at severe risk of losing the confidence of the main funders and if that had happened we would have been unable to make any payments because they wouldn't have released cash to us.
Q. Yes. That's where the shoe pinches, isn't it? Once you had embarked upon this particular
venture
with this contractor, you were effectively in a trap because you would not otherwise know how to account to your funders as to what on earth you were doing with their money. That was your problem, wasn't it?
A. That's a problem, sir, you're quite right, and to make adjustments, if you like, or to change your form of contract or something big, something major in terms of the process is
very
difficult. It's not a commercial set up where you make your own decisions with your own money. It's something that you have to be -- we are accountable to many bodies. It wasn't just Lottery. There were other bodies too that funded the project.
(Emphasis added)
view,
pure speculation. However, I consider that it was to some extent remiss of Mr Thomsett not to seek specialist advice sooner than he did.
very
aggressive and claims minded approach to this project and were prepared to take every advantage of HEL's lack of experience in this field. Against this background it is understandable that HEL thought that its benefactor, Lord Sugar, might be able to bring some pressure to bear on STC to improve its performance. As Mr Thomsett put it, Lord Sugar could be
very
persuasive and even STC's Mr Kent was not immune to Lord Sugar's powers of persuasion.
Aviva's
position as bondsman. Mr Wilmot-Smith advanced
various
ingenious arguments as to why paying money in order to keep an incompetent and under resourced contractor on site for longer than he would otherwise have been was likely to aggravate the position, rather than ameliorate it. For example, he submitted that if the contractor was steadily becoming further and further behind, the longer he stayed on site the greater would be the liquidated damages for which he would become liable. Further, he submitted that it might be increasingly expensive to secure a fresh contractor to complete the work as the quantity of work remaining outstanding diminished and, the longer the delay, the greater the risk that market conditions might have changed adversely by the time the employer went out to tender.
The submissions of the parties on the discharge of the bond
HEL's case
(1) In relation to the general rule that a surety will be discharged if there is avariation
to the principal contract, Mr Thomas submits that this is only the case if the
variation
of the principal contract is such that it increases the risk of default by the principal and consequently the likelihood that there will be a call under the bond.
(2) This, he says, is to be contrasted with a
variation
which merely affects the amount of the surety's ultimate liability but leaves the risk of default unchanged: he relies on a statement to this effect in Andrews and Millett, Law of Guarantees, 5th edition, pages 362-3.
(3) The payment of sums on account of claims is only alleged, or can only be alleged, he submits, to create or increase indebtedness:
Aviva
has not explained how the payments increased the risk of STC not performing the contract.
(4) It cannot be said that the original obligations of the contract were swept away and that a new obligation was put in its place that did not fall within the bond. In support of this submission he relies on Wittman
v
Willdav [2007] EWCA Civ 824.
(5) Alternatively, the Side Agreement was an alteration of the terms of the building contract within the meaning of the indulgence clause in the Bond.
(6) The payment of a sum on account of claims was a forbearance or forgiveness in respect of the requirement to comply with the provisions of the contract before any payment in respect of loss and expense could be made under the terms of the building contract.
Aviva's
liability under it. This, of course, has the consequence that HEL cannot make any claim in respect of the £750,000 (which is why it is Mr Thomas's alternative case). In support of this submission he relies on the decision of the House of Lords in Trade Indemnity Company
Ltd
v
Workington Harbour and Dock Board [1937] AC 1.
Aviva's
case
v
Brunskill (1878) 3 QBD 495, as set out in the judgment of Cotton LJ, at 505:
"The true rule in my opinion is, that if there is any agreement between the principals with reference to the contract guaranteed, the surety ought to be consulted, and that if he has not consented to the alteration, although in cases where it is without enquiry evident that the alteration is unsubstantial, or that it cannot be otherwise than beneficial to the surety, the surety may not be discharged; yet, that if it is not self-evident that the alteration is unsubstantial, or one which cannot be prejudicial to the surety, the court, will not, in an action against the surety, go into an enquiry as to the subject of the alteration, or allow the question, whether the surety is discharged or not, to be determined by the finding of a jury as to the materiality of the alteration or on the question whether it is to the prejudice of the surety, but will hold that in such a case, the surety himself must be the sole judge whether or not he will consent to remain liable notwithstanding the alteration, and that if he has not so consented he will be discharged."
(My emphasis)
Aviva
did not consent to this agreement. Third, it is not self-evident that the alteration is "unsubstantial" or one which cannot be prejudicial to the surety. Accordingly, the court will not go into the merits of the alteration or the question as to whether or not it is prejudicial to the surety, but will allow the surety to treat himself as discharged if he so elects.
variation
of the building contract, was conduct that was prima facie prejudicial to the interests of
Aviva,
as bondsman, with the result that
Aviva
is entitled to treat itself as discharged. In support of this submission he relies on the case of General Steam Navigation Company
v
Rolt (1858) 6 CB (NS) 556.
The principal authorities
v
Brunskill. The plaintiff let a farm, together with 700 sheep, on a yearly tenancy to Mr George Brunskill. George Brunskill, together with his brother Robert and others, entered into a bond to guarantee the redelivery at the end of the tenancy of the land and the flock in good order and condition. The plaintiff and George Brunskill subsequently entered into an agreement by which George Brunskill agreed to surrender a field, known as Bog Field, in consideration of a reduction in the annual rent of £10. George Brunskill subsequently went bankrupt and the tenancy was determined. Under the terms of the bond arbitrators were appointed to assess the condition of the flock, which they found to be reduced in number and in poor condition. Damages were assessed at £132. The plaintiff claimed this sum from Robert Brunskill under the bond.
variation
in the terms of the tenancy. The defence was upheld by the Court of Appeal. Much of the argument in the case concerned the question of whether or not the
variation
in the tenancy altered the risk of default in a manner prejudicial to the surety. This question was left to the jury.
Aviva
(the restriction on claiming liquidated damages prior to 31 May 2003) or were "unsubstantial" (the restriction on initiating a dispute resolution process).
Aviva
was entitled to rely on the Side Agreement irrespective of whether or not the extent to which it
varied
the terms of the building contract. The response from Mr Thomas was that "the alteration" to which Cotton LJ referred several times must be an alteration to the principal contract.
view,
in the context of this passage a separate agreement that was made in relation to the principal contract would only be relevant if it
varied
the terms of the contract guaranteed.
v
Brunskill. It was a clear example of a
variation
to the contract guaranteed and so I think it most unlikely that Cotton LJ was intending to lay down a rule of much wider application than was necessary to decide the issue before him.
v
Rolt (1858) 6 CB (NS) 556. Once again, the facts of the case are important. The company contracted with a Mr Mare to build an iron paddle-wheel steamship to certain specifications. The price was £14,120, to be paid in four equal instalments (for some reason that is not apparent from the report each of the instalments was in fact in the sum of £3,500). The third instalment was to be paid when the
vessel
was launched and the final instalment when the
vessel
had been completely finished and delivered. Mr Mare's obligations under the contract were guaranteed by the defendant.
vessel
was ready to be launched, although it had not in fact been launched, and thereafter the company paid £1,000 on 11 August 1855 and £2,000 on 13 September 1855, by which time the
vessel
was still not completed. On 25 September 1855 Mr Mare was declared bankrupt.
vessel
was not completed until 22 November 1855 (I think that a separate reference in the report to December must be an error). The cost incurred by the company of completing the works was £1,629. In addition, the company claimed £700 by way of liquidated damages. Thus the sums paid in advance in August and September, which amounted to £3,000, exceeded the cost of completing the work and the associated damages for delay. It is therefore not difficult to see that the advance payments were likely to have prejudiced the surety.
variation
of the terms of the contract with the principal discharges the surety". However, it is difficult to discern from the report how the
variation
came to be effected: the pleaded case appears to have been that the payments were made "by arrangement" between the company and Mr Mare. In order for there to have been a
variation
to the contract, one would expect to see some consideration from Mr Mare in return for the advance payments. There is no mention of any consideration in the report.
variation
of its terms. I am inclined to doubt whether Mr Mare could have compelled the company to make the payments in advance of the due date if it had changed its mind and had decided not to pay the money as promised.
very
strongly on a passage in the short judgment of Pollock CB dismissing the appeal, in which he said this:
"Now, certainly, prima facie, the withdrawal of a fund which is a security for the thing in respect of the not doing of which he is now called upon to pay damages is a prejudice to the surety…he is deprived of the security of the fund out of which the company might in the first instance have indemnified themselves… Prima facie, the surety was prejudiced by the existing state of things. Whether there could have been any proof to shew, that, notwithstanding the appearance of prejudice, in reality none was or could be sustained, it is not at all necessary to inquire."
Ltd
v
Workington Harbour and Dock Board [1937] AC 1. The facts are remarkably close to those of the present case. The Board entered into a contract for the enlargement of its dock. It required the contractors to procure a guarantee in the sum of £50,000 for the due performance of the contract. In the course of the work the contractors encountered an unexpected quantity of water in the soil, and the expense of pumping it out was such that they could not continue the work without further funds. By two separate agreements in writing, the Board advanced the contractors the sums of £20,000 and £25,000, to be repaid on certain terms. In spite of this the contractors went into liquidation and failed to complete the work.
insurance
or a contract of guarantee. The second point raised by the surety was that, by lending the contractors the two sums of £20,000 and £25,000 during the progress of the works without the knowledge of the surety, the Board altered the contract and so discharged the surety from liability under the bond. Further, and in any event, it was argued that the engineer's certificate for £78,785, on which the action was founded, could not support a judgment for £50,000 because the amount of the unpaid loan, for which the surety contended it was never liable, had not been ascertained. Accordingly, the true amount for which the contractors were liable under the principal contract, and hence the liability of the surety, had not been established.
"Provided always and it is hereby agreed and declared that the Surety shall not be released or discharged from the above written Bond by any agreement which may either with or without the assent or notwithstanding the dissent of the Surety be made between the Contractors and the Owners or between the Contractors and the engineers in the contract mentioned for any alteration in or to the said works or the contract or any forbearance by the Owners or by the said engineers whether as to payment time performance or otherwise howsoever or by any dealing or transaction which may take place between the Contractors and the Owners . . ."
The words of this proviso are
very
wide, particularly the inclusion of the phrase "or by any dealing or transaction which may take place between the Contractors and the Owners".
"It was then said by [the Board] that though the loans and the certificate could not be justified under the original contract yet the proviso to the condition of the Bond expressly preserves the liability of the surety. I will read it. [Lord Atkin then read the proviso]. The words "any arrangement (sic) . . . for any alteration in or to the said works" arevery
wide. Probably they would have to be cut down so as not to include such changes as had been suggested as substituting a cathedral for a dock, or the construction of a dock elsewhere, or possibly such an enlargement of the works as would double the financial liability. An author of great authority, happily still with us, suggests that such words only relate to alterations "within the general purview of the original guarantee". But in my opinion the loan contracts were not alterations of the original contract at all. The contract was for the construction of specified works at specified prices. The loans were independent borrowings to enable the contractors to perform the construction contract. The position is in my opinion just the same as if the contractors had borrowed the money from their bank, or directly from the Trade Facilities Board, and had charged their payments under certificate with repayment by proportionate deductions. The loans were, of course, connected with the contract and were made for the purpose of performing the contract. That does not make them alterations of the contract. It is true that the terms of repayment involve an alteration in the deductions agreed in the contract the terms of which are altered in this respect; and the proviso would prevent the guarantors from relying on any such alteration. But this is a form of repayment the opportunity for which is long past; and in my opinion it has no affect in altering the primary obligation which arises out of an independent contract with the guarantors never undertook should be performed.
. . . I think that the guarantors never came under any obligation in respect of the new and uncontemplated burden of loans for £45,000, and are not liable for any sum in respect of such sums or interest."
Curiously, Holme
v
Brunskill was not cited in the argument before the House.
v
Dobbs [2005] 2 Lloyd's Rep 588, was relied on by both parties. The law in relation to indulgence clauses was examined in that case. The clause in question stated:
"2.3 The Guarantor's liability under clause 2.1 is not affected by an arrangement which the Bank may make with the company or with another person which (but for this clause 2.3) might operate to diminish or discharge the liability of or otherwise provide a defence to a surety.
2.4 The Bank may at any time as it thinks fit and without reference to the Guarantor:
2.4.1 grant time for payment or grant any other indulgence or agree to any amendment,variation,
waiver or release in respect of an obligation of the Company under the Loan Agreement;
2.4.4 compound with, accept compositions from and make other arrangements with the Company or a person or persons liable on other securities or guarantees held or to be held by the Bank."
vital
question for the court is whether the Company's liability under this agreement is something which Mr Dobbs has guaranteed". He concluded that a replacement on terms so different from the original agreement, as occurred in that case, cannot be an "amendment or
variation"
of the initial contract (paragraph 13). It seems to me that the effect of this finding is that the presence or absence of an indulgence clause in the initial contract became effectively irrelevant.
14. Authority
"It is, of course, the law that a materialvariation
in the contract between the creditor and the principal debtor will discharge the guarantor, unless the
variation
is one to which he assented or which is provided for in the contract of guarantee. In his book (1898) on the Law of Principal and Surety, Mr Sidney Rowlatt (as he then was) said this:-
". . . it is apprehended that assent, whether previous or subsequent to avariation,
only renders the surety liable for the contract as
varied,
where it remains a contract within the general purview of the original guarantee . . . . If a new contract is to be secured there must be a new guarantee."
This passage was retained in the second edition of the book (1926) edited by the son of (the by then) Rowlatt J with his father's encouragement and was adopted by Lord Atkin in his speech in Trade Indemnity CoLtd
![]()
v
Workington Harbour and Dock Board [1937] AC 1, 21 with whom the other members of their Lordships' House concurred. The actual decision in that case was that a loan of £45,000 made by a building owner to a building contractor did not constitute an agreement " . . . for any alteration in or to" the building contract which the company had guaranteed. In much the same way I do not think that a facility agreement, whereby it was agreed that the debtor's account with the creditor should be debited with sums due under the building contract to which the debtor was a party, can be said to be an amendment or
variation
to a contract of loan. Even if, however, it could be said that such an agreement was, in principle, such an amendment or
variation,
the question would still arise whether it was "within the general purview of the original guarantee". Lord Atkin's approval has been followed in the later cases of The Nefeli [1986] 1 Lloyds Rep 339, 345 per Bingham J and Melvin
v
Poseidon (The Kalma) pages 11-12 of transcript of 18th June 1999 per Cresswell J.
15. We were referred to British Motor Trust CoLtd
![]()
v
Hyams (1934) 50 TLR 230 in which a Mr Lord acquired two motor coaches under two hire-purchase agreements from the claimants and persuaded his mother-in-law to guarantee his obligations by a contract indorsed on the agreements in the following terms:-
"We . . . guarantee the due and punctual payment by the . . . hirer of all . . . moneys payable by him under the within written agreement . . . and we further agree that this guarantee shall not be avoided . . . by the owners and the hirer making anyvariation
in the terms of the said agreement . . . provided that no
variation
shall make us liable for a greater maximum sum under this guarantee than that for which we are at present or may become liable under the present terms of the said agreement."
Mr Lord fell into arrears and the claimant, instead of resuming possession, made a new single agreement with him by which the two earlier agreements were consolidated and thevehicles
were regarded as being hired together so that Mr Lord could not acquire property in any one
vehicle
unless he paid all instalments due on both
vehicles.
Branson J (to whom Rowlatt J's work does not seem to have been cited) described the clause permitting
variation
to be:-
"so wide that it was almost impossible to put any limit to the power tovary."
and added:-
"It might be that the position of the debtor was so altered that he would be less able to repay the guarantor, but even such a change was not beyond thevery
wide power of
variation
contained in the guarantee."
16. I would not wish to doubt the correctness of this decision on its facts but I would make two observations. First it is important to distinguish between a truevariation
of an existing obligation and the entering of what is in fact a different obligation even though it may purport to be no more than a
variation.
In that sense it is perfectly possible (and, indeed, right) to put a "limit to the power to
vary".
Secondly the proviso to the guarantee ensured that in any event Mr Lord's mother-in-law was never going to be liable for more than whatever she would have been liable for under the guarantee in its unamended form. This is an even tighter proviso than a monetary limit such as that provided for in Mr Dobbs' guarantee. The tightness of the proviso would, no doubt, be one justification for giving a wide construction to the
variation
provision and enabling the new arrangement to be regarded as a
variation
of the old one.
17. The first of the above observations derives some support from Samuels Finance Group Plcv
Beechmanor
Ltd
and others (1993) P&CR 282 where Lloyd LJ said after setting out the first of the above citations of Branson J in Hyams:-
"One can perhaps imagine changes falling short of a novation which would yet be so fundamental that they could not properly be described as avariation
at all. I will not attempt to say where the line is to be drawn."
It is, indeed, not easy to draw a hard and fast line between permissible and impermissiblevariations
but in the present case the obligations arising from the 1999 facility are so different from those arising under the original pair of loan agreements that I have no difficulty in saying that the line has been crossed. In the Samuels Finance Group case itself the
variation
was comparatively minor and could well have been said to be within the "purview" of the original contract.
18. Neither of the above authorities referred to the requirement that anyvariation
(even if there is advance agreement to a
variation
of the underlying loan agreement) must be within the "purview" of the agreement, but the passage in Rowlatt remains in the 5th edition (1999) para. 4-72 and, in my
view,
this requirement is still law."
view
this case is really authority - if further authority is needed - for the proposition that, where the bond provides that it will not be invalidated by any alteration or
variation
to the principal contract or the surety agrees to the
variation,
the surety will only be liable if the contract as
varied
remains a contract within the general purview of the original guarantee. What this means, in the words of Longmore LJ, is that the question for the court is whether the (new) agreement, for the breach of which the claimant is suing on the bond, is properly to be regarded as an amendment or
variation
of the principal agreement which is within the purview of that original agreement (paragraph 19).
The payment of £500,000 in December 2002
view,
this did not constitute a
variation
of the building contract. STC was already under an obligation to proceed diligently with the work and the production of a programme was part of the usual obligations of a main contractor (clause 5.3.1.2 provided that, as soon as possible after the execution of the building contract, STC was required to produce a master programme). I find that at the time when this payment was made there was no agreement to waive any entitlement to liquidated damages, either wholly or in part. There was just the bare agreement in the terms that I have outlined. In any event, if there had been any
variation
of the building contract it would have fallen within the terms of the indulgence clause.
v
Brunskill in relation to the first payment of £500,000. If he is to succeed in relation to that payment, he can only do so, if at all, by
virtue
of the decision in General Steam Navigation Company
v
Rolt.
The scope of the guarantee
varied,
then the surety would be discharged unless (a) one of the exceptions to the rule in Holme
v
Brunskill applied or (b) the
variation
fell within the purview of the indulgence clause or, possibly, (c), the
variation
only increased the extent of a potential default, not the risk of it occurring.
view
that the extent to which the building contract was
varied
by the Side Agreement was either beneficial to
Aviva
or of minimal consequence and therefore fell within the exceptions to the rule in Holme
v
Brunskill. But this does not decide the question of whether on a true construction of the bond it covered STC's potential liability if it did not repay the sum advanced. Mr Wilmot-Smith accepted that the Side Agreement, once made, had retrospective effect.
v
Dobbs Longmore LJ appears to have made an overall assessment of the initial obligations and concluded that the new obligations were so different that they could not properly be described as an amendment or
variation.
In addition, he emphasised the distinction between a true
variation
of an existing obligation and the entering of what is in fact a different obligation even though it may purport to be no more than a
variation
Subject to the two minor
variations
already mentioned, the terms and operation of the building contract were left unaffected by the making of the Side Agreement. It was a separate and additional arrangement between HEL and STC containing an entirely new obligation to repay the advance immediately if the terms of the Side Agreement were not met.
value
of STC's claims would be in the region of the £1 million that HEL was proposing to advance.
Aviva
be deemed to have assumed, for no additional premium, the additional risk of STC not complying with the terms of the Side Agreement and being unable to repay the advance if called upon to do so as a result when the making of the advance (a) did not in any way limit or reduce the scope of STC's obligations under the building contract that it had guaranteed and (b) took place without
Aviva
knowing anything about it? The answer to this question, in my
view
has to be: "it should not".
Aviva
under the bond. It follows, therefore, that
Aviva
has no liability in respect of STC's failure to repay the £750,000. This conclusion disposes of HEL's primary case in relation to the Side Agreement.
The consequences of the payment of £500,000 on 30 December 2002
variation
of the contract guaranteed.
verge
of insolvency when the payment was made, as in the General Steam Navigation case, with the result that the money is effectively lost. This would, I readily accept, be prima facie prejudicial to any surety who had guaranteed the obligations of the contractor. However, if a contractor asserts that he has already been caused loss and expense as a result of the conduct of the employer or his agents, to pay him a reasonable sum on account of that claim pending its final resolution is not, I would have thought, necessarily prejudicial to any surety. The contractor's cash flow may be
very
tight and he may be unable to absorb the loss and expense whilst at the same time maintaining the necessary resources on site to complete the contract in accordance with the programme. On the other hand, he may already be insolvent so that the advance will do no more than stave off the inevitable. In my
view
it is only in the latter situation, not the former, that there is any potential for prejudice to the surety.
v
Rolt is authority for the proposition that if an employer acts in a manner in relation to the principal contract which, whilst not amounting to an alterations of its terms, is prima facie prejudicial to the surety who has guaranteed the contractor's obligations under the principal contract, the surety will be discharged (absent any relevant indulgence clause in the guarantee). My conclusion is tentative because I accept the observation, forcefully made by Mr Thomas, that if my conclusion is right it is
very
strange that this potentially fruitful seed has not sprouted. General Steam Navigation Company
v
Rolt has not been referred to in any of the subsequent authorities cited to me, apart from Andrews and Millett, Law of Guarantees, 5th edition, page 363 - which seems to treat it as an extension of the rule in Holme
v
Brunskill. However, for the reasons that I have given, I am not convinced that this is correct. It seems to me that the rule in Holme
v
Brunskill applies only where the principal contract has been
varied.
v
Condor
Insurance
Ltd
[2006] 2 Lloyd's Rep 525, which concerned the question of whether the conduct of the parties had amounted to a
variation
of the principal contract. There was an application for summary judgment in a claim under a guarantee. It is not necessary to refer to the facts. Having cited the passage in the judgment of Cotton LJ in Holme
v
Brunskill, Mr Justice Christopher Clarke went on to say this:
"36. The basic principle underlying these cases - which is one of strict application - is that a guarantor will only be liable in respect of the obligation that he guaranteed. Thus if X guarantees a debt agreed to be payable within a specified time he is not liable in at least two cases:
(a) if the creditor advances money or supplies goods on terms that the money is repayable or the price payable immediately; or
(b) if the creditor and his debtor agree avariation
of the contract whereby the debtor is bound to pay earlier, unless such an agreement is, on the facts, obviously incapable of prejudicing the surety.
In both cases the transaction between the debtor and creditor which a guarantor is called upon to underwrite is not the one contemplated by the guarantee: in the first case because the transaction with the debtor was never that character; in the second because the debtor and his creditor have agreed avariation.
37. But a debtor who is entitled to 55 days credit is not bound to wait until all of the 55 days have elapsed. He can, if he chooses, pay before then. The guarantor is not released because he does so, even if the early payment is made at the creditor's request. Such a payment is not inconsistent with the contract guaranteed and involves novariation
of it.
38. If, however, the debtor has undertaken a binding obligation to pay an early the contract will have beenvaried.
The debtor is no longer free to choose whether to pay at the expiry of the credit period. He is bound to pay it before. The contractual obligations into which he has entered are not the same as those that the guarantor guaranteed."
One of the central issues on the application in that case was whether the agreement between the parties by which an advance payment was made amounted to a legally binding agreement. Since Christopher Clarke J concluded that it could not be said that the guarantor had no realistic prospect of showing that there was a binding agreement, the application for summary judgment in the claim under the guarantee was refused.
vary
the contract: the real test was whether as a result of a change in the arrangements there was a real chance that the guarantor might have been prejudiced. Christopher Clarke J said, at paragraph 50: "So expressed, the proposition appears to me too broad". A
variant
of this submission was that if a debtor makes an advance payment in response to a threat by the creditor to break his contract with the debtor and the creditor (as was alleged in that case) threatens to refuse to supply on the contractual terms, or at all, then the guarantor is discharged. However, that is not a type of situation that arose in the present case and so I need not say anything about it: in any event, since Christopher Clarke J was not proposing to give summary judgment he did not consider that alternative submission at any length.
v
Brunskill and the rule, if it is a rule, in General Steam Navigation Company
v
Rolt. In the former, any alteration of in the terms of the principal contract will discharge the surety unless it is self-evident without inquiry either that the alteration cannot be prejudicial to the surety or that it is of no significance ("unsubstantial", to use Cotton LJ's word). However, in the latter Pollock CB set that the conduct of the employer must be prima facie prejudicial to the surety if it is to discharge the surety from liability. This is a higher threshold for the surety to cross. The observations of Christopher Clarke J in ST Microelectronics seem to me to reinforce the distinction between a
variation
of the terms of the principal contract and a (non-binding)
variation
in the mode of its performance.
v
Rolt has the effect of discharging
Aviva
from liability I consider that the following factors are relevant:
(1) By December 2002 it was apparent to HEL that STC was under resourced and was falling steadily behind programme.(2) By the same time it was or should have been apparent to HEL that the reason for this was STC's poor financial position.
(3) STC had made numerous unsubstantiated claims under the contract and was asserting that it had suffered substantial loss and expense as a result of instructions issued by the architect.
(4) It was accepted within HEL and its professional team that some of STC's claims were probably
valid
and would in all probability be substantiated to some extent.
(5) Whilst the precise
value
of STC's claims was a matter of speculation, it was not unreasonable for HEL to think that those sums might exceed £1 million. Before the Side Agreement was concluded, but
very
shortly after the payment of the first £500,000, HEL was given a figure of £1.8 million by its Quantity Surveyors as the best estimate of the likely settlement
value
of STC's claims.
(6) The figure of £1 million was arrived at as a result of the negotiations chaired by Lord Sugar in November 2002.
(7) HEL considered that to make the advance of £1 million was in its interests for two reasons. First, to avoid a premature referral to adjudication by STC, the probable results of which were anticipated to be the diversion of resources from site and an award in favour of STC. Second, that STC's cash flow was tight and STC had promised that it would achieve a proper level of progress on site if the advance was made.
To the extent that they were not common ground, in the light of the evidence that I have already summarised I find as a fact that all these factors were present.
value
and that the likelihood was that STC would be successful if it referred its claims to adjudication, even if not to the full extent claimed. STC's claims by then amounted to some £4 million.
value
in excess of £1 million. It is a fair inference that this is what HEL did think, otherwise it would probably not have agreed to make a payment on account of that amount. The fact that on 2 January 2003 the Quantity Surveyors suggested a figure of £1.8 million as a probable settlement
value
of STC's claims suggests that a figure in excess of £1 million could well have been in HEL's mind in December 2002.
(1) It appears that STC's financial difficulties were probably not as bad in December 2002 as they were some 3-4 months later.(2) There was no reason to question STC's assertion that if the payments were made it would increase its resources on site. Indeed, HEL could reasonably expect that an injection of funds would have this effect.
(3) HEL was not proposing any amendments to the terms of the building contract that would increase the risk of default by STC.
(4) There was no other basis for thinking that the making of the advance would increase the risk of default by STC, although there was the risk (which did not exist before) that STC would not be able to repay the advance if it did not substantiate its claims.
v
Rolt that is what is required if the surety is to be discharged without any further investigation.
v
Brunskill, I might have concluded that it was not self-evident without inquiry that
Aviva
could not be prejudiced by the advance. This was a possibility, although not the likelihood.
v
Brunskill does not apply. In any event, to the extent that the agreement of 16 December 2002 may have
varied
the terms of the building contract, such a
variation
would fall within the scope of the indulgence clause.
The consequences of the payment of £250,000 and the Side Agreement
varied,
the terms of the building contract were beneficial to
Aviva
and of minimal consequence, respectively, the rule in Holme
v
Brunskill does not apply. I have already rejected Mr Wilmot-Smith's submission that the rule is engaged simply by the making of an agreement that is related to the principal contract.
Aviva,
and consequently within the rule in General Steam Navigation Company
v
Rolt, I reject that submission also for much the same reasons as those I have given in relation to the payment of the first instalment of £500,000. In the following paragraphs I will explain further why I have reached this conclusion in relation to the £250,000.
Q. Well, you knew, didn't you, at the time that you were making these payments that you were making it to a contractor who was financially in dire straits because they were not able to pay their debts as they arose?A. That's going a little further than I would, sir. I knew they had financial challenges. I wouldn't have said they were in dire straits, but certainly we knew they had issues.
Q. If they couldn't pay their sub-contractors, they couldn't pay their debts as they arose, could they?
A. Sir, it could be that they couldn't fail but they were reluctant to pay. We didn't know whether they were simply being dishonest, if you wish, rather than simply unable to pay. We didn't know which was which.
Q. You took no steps to discover what their true financial position was did you?
A. The only steps we could take were looking at their accounts, which we did and we tracked but in terms of published accounts there is such a historic record that they are not
very
useful on a position that's changing quite frequently.
Q. The published accounts which you looked at were in 2000?
A. Yes, exactly.
Q. You knew when you looked at those that there was a real risk of deterioration since then didn't you?
A. No, sir.
Q. You didn't think there was a real risk of deterioration of the accounts after --
A. I did think there was. I didn't know there was. I'm sorry, your question was did we know that there was a risk not ---
Q. A risk. You must have known there was a risk. Whether it eventuated or not is another question but you must have known there was a risk of insolvency?
A. Of course, yes. With any company that would be the case.
Q. A risk of insolvency against the background of a contractor producing work product at roughly one third of the required rate. Correct?
A. Yes, sir.
Q. One of the classic signs of a contractor that is not in good financial shape, isn't it?
A. Yes, sir.
Q. A contractor that is not paying its sub-contractors as and when it should: again, a sign of a contractor not in good financial shape, isn't it?
A. Yes, sir, but we didn't know that to be the case. It was anecdotal evidence only, but yes, yes.
Then, after Mr Thomsett had been taken to the terms of his letter of 20 December 2002 (the earlier
version
of the Side Agreement), the cross examination proceeded as follows:
Q. Yes, so on no
view
by 28 February could the contractor have been otherwise than in breach of its obligation to progress the works as quickly as possible?
A. Yes, sir, yes.
Q. And therefore on no
view
otherwise than that you were entitled in January and February of 2003 to demand repayment of those sums paid, the half million?
A. Yes, sir, but were we to have done so, there is no doubt that there would have been a halt called to the works, a complete halt, as opposed to 50 per cent of the progress that you describe.
Q. And because you had not got yourself ready to deal with any adjudication as you would have been had you taken the architect's advice of a year earlier, you felt it was better to give this failing contractor another quarter of a million pounds rather than operate the deal you thought you had on 20 December?
Aviva's
case, which is clearly correct, that the terms of HEL's letter of 20 December 2002 were never agreed. Accordingly, as at 26 February 2003 HEL was not in a position to demand the repayment of the £500,000 on the ground of non-performance by STC because the term which subsequently gave rise to that right had not by then been agreed.
MR JUSTICE EDWARDS-STUART: Yes. But Mr Thomsett, what I am asking you is had you taken on board the difference between being paid for materials that were delivered to site and being paid for materials that were not delivered to site and were still offsite?
A. My Lord, yes. I was taking advice at the time. This was the quantity surveyor specifically explaining those points.
Q. Yes. And so what was your understanding, then, of what was going on?
A. Our understanding was that the sub-contractor was due payment for some of the materials offsite, so where --
Q. And was not being paid?
A. I did not know that.
Q. Well, why were you being told about the sub-contractors' payment for goods offsite if there was not some sort of row about it?
A. I think again, my recollection, and it is a while ago, was that there were, as there are, discussions between the quantity surveyor and the
various
sub-contractors and the word had got round through those paths. I do not think there was anything formal in terms of correspondence to tell us that.
MR WILMOT-SMITH: So what Sir Alan was suggesting was a way to do two things: one was to give the contractor the wherewithal to pay his sub-contractors for offsite materials?
A. Yes, sir.
Q. And secondly, to make a payment on account of claims which were then not substantiated and, on the architect's advice, might never be substantiated?
A. Well, except that the contractor said they would in due course provide that substantiation and the particulars needed.
Aviva
as the bondsman. Accordingly, the making of the payment and the Side Agreement did not discharge
Aviva
from liability under the guarantee.
The payment for the offsite materials
Aviva
was advanced by a last-minute amendment to the pleadings made on the first day of the trial. Mr Thomas had had barely 24 hours notice of it. However, having thought about it overnight he considered that he was prepared to deal with the point of principle, even though
Aviva
had not provided any details of the timing or the extent of the payments.
various
safeguards for its payment for the offsite materials. Where HEL paid for off site materials the relevant sub-contractor or supplier was required to sign a Certificate of Indemnity by which title in the materials passed to HEL and the sub-contractor undertook to keep the materials
insured.
Aviva
by HEL's payments for offsite materials, even if the making of such payments amounted to a
variation
of the building contract. Anyway in the latter event, it would be a
variation
falling within the scope of the indulgence clause.
The indulgence clause
". . . no alteration
(i) in the terms of the said Contract made by agreement between the Employer and the Contractor or
(ii) in the extent or nature of the Works to be constructed and completed thereunder; and
(iii) no allowance of time by the Employer or the Architect under the said Contract nor
(iv) any forbearance or forgiveness in or in respect of any matter or thing concerning the said Contract on the part of the Employer or the said Architect
shall in any way release the Surety from any liability under the above-written Bond."
Aviva
could rely even in the absence of this clause. As to (ii), this is clearly not applicable. Thus the argument concerns (iii) and (iv). The issue being whether the arrangements by which the payments of £500,000 and £250,000 were made fell within these provisions.
view
be described as a forbearance from insisting on anything.
variation
plainly did increase the risk of default, namely by adding the risk of defaulting on the obligation to repay the money advanced if the terms of the Side Agreement were not met. So I reject Mr Thomas's submission that, if the Side Agreement was a
variation
of the building contract, it did not increase the risk of default.
Aviva
any liability for STC's failure to repay the £750,000.
The scope of the recovery under the bond
Aviva
has not been discharged from liability under the bond and that it is not liable for STC's default in failing to repay the £750,000 advanced, the remaining question is what losses HEL can recover.
(1) On 29 May 2003 he arranged a meeting with Mr Greenough, STC's Managing Director, which was attended by Mr Ronalds and Mr Barbour. Mr Greenough explained that STC faced serious cash flow difficulties and that it had lost the confidence of its sub-contractors. He said that there was little or no chance of completion by the end of July 2003.(2) At a meeting on 5 June 2003 HEL was told that STC anticipated completing the works by the end of September 2003.
(3) On 17 June 2003 Mr Thomsett was told that Mr Greenough had left STC.
(4) Towards the end of June 2003 some of STC's sub-contractors stopped working and others were threatening to remove on-site materials for which HEL had paid. By 1 July 2003 HEL had heard that STC's mechanical sub-contractor, Kershaw, was intending to remove its materials from site the following day.
(5) On 2 July 2003 STC abandoned the works. Two sub-contractors had already indicated that they were not going to carry out any further work until they were paid. Later that day Mr Thomsett heard that STC had "gone bust".
(6) On either that or the following day, 3 July 2003, Mr Thomsett learned that everyone employed by STC had been made redundant save for its chief surveyor.
"We refer to the above project and the Building Contract between us dated 5 March 2002.
This notice should be read after our first letter of today's date.
We,Hackney
![]()
Empire
Limited, hereby determine your employment under the Building Contract, pursuant to clause 27.3.4. In accordance with clause 27.1, this notice will take effect from this Wednesday, 23 July 2003.
We take this opportunity to remind you of the following:
? We may use all temporary buildings, plant, tools, equipment and Site Materials and you are not permitted to remove them unless you are required to do so by the Architect.
? We reserve the right to pay any supplier or sub-contractor for any materials or goods delivered or works executed for the purposes of the Building Contract before or after the determination of the Building Contract insofar as the price thereof has not already been paid by you. Any sum so paid, we will claim from you as a debt.
We will be sending a copy of this notice to your Bondsman's advisers, says Gallagher CS."
view
did amount to a breach of contract, and probably a repudiatory breach at that. Although there was not complete abandonment of the site by the time the administrator was appointed, the following observation of O'Donnell J in Galway City Council
v
Samuel Kingston Construction [2010] 3 IR 95, at 120, is not without relevance:
"It is difficult to conceive those circumstances where it could be said that notwithstanding abandonment of the site a contract still existed so that the employer must continue to perform it and would be left to its remedy in damages. I would not like to add further uncertainty to the area of building contracts by endorsing the suggestion that abandonment of the site can be either a repudiatory breach or a mere breach depending on the circumstances, some of which may not be known at the time and can only be determined after the fact by an arbitrator."
v
General Surety (1994) 66 BLR 72.
valid
claim under the bond. It held that clause 27.2 was intended by the parties to be an exclusive code setting out the party's rights in the event of the appointment of an administrative receiver. After noting the fact that, in contrast to clause 27.1, clause 27.2 was not expressed to be without prejudice to any other rights or remedies which the employer may possess, Peter Gibson LJ said, at page 85:
"If the parties wished to allow rights or remedies other than those set out in clause 27.2 and 27.4, to be exercisable, then they would in my judgment have put in express in words to that effect. Accordingly, I cannot accept this submission either."
Summary and answers to the issues
1. Whether or notAviva
is discharged from liability under the Bond arising from:
1.1 A payment of £500,000 made by HEL to STCL on 31 December 2002;No.1.2 The execution of the Side Agreement of 26 February 2003;No.1.3 A later payment of £250,000 by HEL to STCL pursuant to the Side Agreement; orNo.1.4 The amendments to the Side Agreement on or about 24 April 2003.No (by agreement).2. If
Aviva
is not discharged from liability under the bond, does its liability extend only to the payment of liquidated damages of £205,000 which had accrued due at the date of termination?
No.2.1 If not, for which if any of the matters set out at paragraph 39 of the Particulars of Claim isAviva
liable? (Quantification to be deferred to a potential quantum trial).
It is assumed that this issue should refer to paragraph 41 of the Particulars of Claim. In relation to the items there set out:a. £205,000.b. Nil.c. Insofar as these losses were caused by STC's failure to give prompt notice of delays in accordance with the building contract, they are in principle recoverable: however, losses consequent upon the delays themselves are not recoverable (item e.ii appears to fall into this category).d. Probably: but this depends on precisely how the increased charges and fees arose.e. Yes.f. Yes.g. These heads of loss are governed by the same principles as set out in c above.h. In principle, yes, to the extent that there is no overlap with the heads of loss listed above.3. Whether or not HEL accepted a repudiatory breach of the Building Contract by STC so as to entitle HEL to claim sums from STC:
3.1 in excess of the liquidated damages accrued under the Building Contract prior to determination; andDoes not arise. HEL is entitled to recover damages at common law because STC was in breach of contract before 2 July 2003.3.2 without the need to comply with clause 27.6.4.2 of the Building Contract's Conditions.Yes, because HEL's right to recover damages at common law is preserved by clause 27.8.4. 4.1 If HEL has not accepted a repudiatory breach of contract, whether or not a reasonable time for HEL to issue a statement or the Architect to issue a certificate under clause 27.6.4.2 has now expired?
Does not arise in the light of the answer to issue 4.2, but HEL accepts that a reasonable time for the issue of a certificate has now expired.
4.2 If so, whether that deprives HEL of any entitlement it otherwise has or may have, in particular under clause 27.6.No, because HEL's right to recover damages at common law is preserved by clause 27.8.5. If
Aviva has not been discharged, what is its liability for interest on the sums claimed by HEL?
The court has not heard full argument on this issue. Accordingly, in the absence of any further directions, this issue will have to be addressed at the assessment of HEL's damages.